Anaheim California Building Consultant Directory

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Contractor Suffolk's Hospital Project Is on Critical List After Steward Health Care Bankruptcy

January 14, 2025 — Richard Korman - Engineering News-Record
Before it was hit by troubles that now threaten to kill it, a new hospital being built by Suffolk Construction in Norwood, Mass., was shaping up as a tale of recovery. The existing hospital on the site had been forced to shut most local operations since a devastating rainfall and flood in 2020. Read the full story...
Reprinted courtesy of Richard Korman, ENR

Best Lawyers Honors Hundreds of Lewis Brisbois Attorneys, Names Four Partners ‘Lawyers of the Year’

September 16, 2024 — Lewis Brisbois Newsroom
(August 15, 2024) - Best Lawyers has selected 171 Lewis Brisbois attorneys across 47 offices for its 31st edition of The Best Lawyers in America. It has also recognized four Lewis Brisbois partners on its "Lawyers of the Year" list: San Diego Partner Gary K. Brucker Jr. (Litigation - Real Estate); Weirton Managing Partner Michelle L. Gorman (Mass Tort Litigation/Class Actions - Defendants); Roanoke Partner Paul C. Kuhnel (Medical Malpractice Law - Defendants); and Los Angeles Co-Administrative Partner Steven R. Lewis (Product Liability Litigation - Defendants). Please join us in congratulating the following attorneys on their Best Lawyers recognition! You can see the full list of attorneys named to Best Lawyers' Ones to Watch in America here. Read the full story...
Reprinted courtesy of Lewis Brisbois

BWB&O’s Motion for Summary Judgment is Granted in a Premises Liability Matter

November 05, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Congratulations to Newport Beach Partner Courtney Serrato and Associate Joseph Real on Prevailing on a Motion for Summary Judgment for their Client! Plaintiff filed a lawsuit alleging negligence and premises liability against BWB&O’s client, a general contractor of a multi-level construction project. Plaintiff was injured after a fall at the construction project and filed suit against BWB&O’s client and another subcontractor. Plaintiff alleged BWB&O’s client was negligent and was responsible for causing Plaintiff’s fall. BWB&O filed a Motion for Summary Judgment arguing under the Privette Doctrine and its progeny, it neither owed nor breached any duty to Plaintiff and that no exception to the doctrine applied. Under the Privette Doctrine, when a person or entity hires an independent contractor to provide work or services, and one of the contractor’s employees is injured on the job, the hirer is generally not liable to the employee. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Rikus Locati Selected to 2024 Northern California Rising Stars!

August 05, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Congratulations to BWB&O’s 2024 Northern California Super Lawyers Rising Stars! BWB&O is proud to announce that Walnut Creek Associate Rikus Locati has been selected to the 2024 Northern California Super Lawyers list as Rising Stars for his work in Personal Injury. Super Lawyers is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The objective of Super Lawyers’ patented multiphase selection process is to create a credible, comprehensive, and diverse listing of outstanding attorneys that can be used as a resource for attorneys and consumers searching for legal counsel. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Stop Losing Proposal Competitions

December 10, 2024 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday here at Musings, we welcome back Matt Handal. Matt (@matthandal) provides proposal writing strategies that actually work at www.howtowritetheproposal.com. He is the author of Proposal Development Secrets, contributing editor of SMPS Marketer, and co-author of the Marketing Handbook for the Design & Construction Professional. His latest experiment is on business letters. It’s frustrating. You’re a great designer or contractor. Clients love you. The problem is you spend hours producing great proposals, but keep losing. Not only that, most of the time you don’t even get short listed. To make matters worse, the clients keep choosing firms you know you’re better than. So they get the contract and you’re left scrambling for work. Even though these firms frustrate you, imagine what it’s like to be them. They’re not the best, or most qualified firm, yet they walk away with the contract. They are not scrambling for work. They’ve got a healthy backlog. Imagine how it must feel to be them. Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Can Businesses Resolve Construction Disputes Outside of Court?

August 19, 2024 — Scott L. Baker - Los Angeles Litigation Blog
Time is of the essence in any construction project. So, if a dispute arises at any point, business owners generally wish to avoid the chance of a time-consuming case going to court. Can California construction businesses manage these disputes effectively outside of court? It is possible in some cases. Business owners should carefully consider these three steps. 1. Go Back to the Contract Even if the contract is at the center of the dispute, it is important to refer to any details regarding dispute resolution included within the document. It is common for contracts to have some form of a dispute resolution clause. In such a case, both parties should follow the steps outlined in that agreement. Read the full story...
Reprinted courtesy of Scott L. Baker, Baker & Associates
Mr. Baker may be contacted at slb@bakerslaw.com

The Privette Doctrine and Its Exceptions: Court of Appeal Grapples With the Easy and Not So Easy

November 18, 2024 — Garret Murai - California Construction Law Blog
In CBRE v. Superior Court, 102 Cal.App.5th 639 (2024), the 4th District Court of Appeal grappled with a thorny and not-so-thorny issue involving injured parties under the Privette doctrine. The less thorny issue was whether application of the Privette doctrine depends on whether a written contract exists between the parties. Spoiler: It does not. The thorny issue was whether the Hooker exception to the Privette doctrine – which applies when a landowner exercises control over a project – should apply where a landowner directs a contractor to perform work that is at odds with legal requirements. The CBRE Case Property Reserve, Inc. owns an office building managed by CBRE in San Diego, California. On April 9, 2019, PRI entered into a lease agreement with a new tenant for a suite in the building. The lease required that PRI perform certain tenant improvements. Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES