Anaheim California Building Consultant Directory

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

NCDOT Aims to Reopen Helene-damaged Interstate 40 by New Year's Day

December 10, 2024 — Derek Lacey - Engineering News-Record
Interstate 40, closed in late September when flooding from Hurricane Helene caused multiple landslides and washouts in the Pigeon River Gorge between North Carolina and Tennessee, is expected to partially reopen on New Year’s Day 2025, more than three months after the storm. Long-term reconstruction plans are still in early development. Read the full story...
Reprinted courtesy of Derek Lacey, ENR
Mr. Lacey may be contacted at laceyd@enr.com

Governor Bob Ferguson’s Recent Executive Orders – A Positive Sign for Washington’s Construction Industry

January 21, 2025 — Ryan Sternoff & Trygve Groh - Ahlers Cressman & Sleight
On January 15th, in his first act as Washington’s Governor, Bob Ferguson signed three executive orders, two of which may have a direct impact by removing some of the “red tape” that stifles Washington’s construction industry. This appears to be a positive sign that the Governor’s office is focused on pragmatic action, rather than partisan politics. Executive Order 25-02 is entitled “Assessing Regulatory Efficiency and Addressing Washington’s Affordable Housing Crisis” and directs all executive and small cabinet agencies (collectively, “State Agencies”) to review their rules and regulations and prepare a report for the Governor’s Office that identifies rules or regulations that impact the construction of new housing. The reports will also identify rules or regulations that are no longer necessary and can be rescinded, rules or regulations that can be amended to speed up housing construction. The reports will include descriptions of proposed amendments to such rules and regulations. The reports must be provided to the Governor’s Office within sixty days. Read the full story...
Reprinted courtesy of Ryan Sternoff, Ahlers Cressman & Sleight
Mr. Sternoff may be contacted at ryan.sternoff@acslawyers.com

Real Estate & Construction News Roundup (12/4/24) – Highest Rate of Office Conversions, Lending Caps for Fannie Mae and Freddie Mac and Affordability Challenges for Homebuyers

December 23, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, infrastructure-related ballot initiatives, U.S. Green Building Council’s success stories, support for sustainable building, and more!

2024 is expected to see the highest rate of office conversions since CBRE began tracking them in 2016. (Nish Amarnath, SmartCities Dive)
The Federal Housing Finance Agency has established lending caps of $73 billion each for Fannie Mae and Freddie Mac, allowing them to purchase a total of up to $146 billion in multifamily loans in 2025. (Leslie Shaver, Multifamily Dive)
A number of infrastructure-related initiatives with the potential to impact facilities managers were on the ballot during the 2024 U.S. presidential election. (Joe Burns, Construction Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Big Data Meets Big Green: Data Centers and Carbon Removal Compete for Zero-Emission Energy

October 15, 2024 — Robert A. James, Sidney L. Fowler & Ashleigh Myers - Gravel2Gavel Construction & Real Estate Law Blog
Artificial intelligence, data centers, carbon removal and zero-emission power may sound like a winning line (plus the Free Space) on a 2024 Buzzword Bingo card. But the concepts have come into dramatic real-world tension as private and public actors seek to accommodate the digital and environmental imperatives for green energy. After years of fairly stable demand, punctuated by declines during the pandemic and economic slumps, electricity demand is projected to double by 2050. A principal cause is the rapid expansion in the power needed to energize and cool servers amid explosive growth in the number and size of data centers, crypto miners, and other point sources of computation. Data centers were 3% of U.S. demand and are projected to be up to 9% or more by 2030; AI will drive a 160% surge in data center demand by 2030. A commentator notes, “We haven’t seen [growth like] this in a generation.” Reprinted courtesy of Robert A. James, Pillsbury, Sidney L. Fowler, Pillsbury and Ashleigh Myers, Pillsbury Mr. James may be contacted at rob.james@pillsburylaw.com Mr. Fowler may be contacted at sidney.fowler@pillsburylaw.com Ms. Myers may be contacted at ashleigh.myers@pillsburylaw.com Read the full story...

A Chicago Skyscraper Cements the Legacy of a Visionary Postmodern Architect

December 31, 2024 — Mark Byrnes - Bloomberg
A handsome and eclectic stretch of buildings along Michigan Avenue known as “Chicago’s Front Door” offers a view that reflects the city’s status as a destination for serious architecture. Louis Sullivan and Dankmar Adler’s Auditorium Building, where a young Frank Lloyd Wright designed interiors, is right there on Grant Park; so is Daniel Burnham’s Railway Exchange, where he drew up the 1909 Plan of Chicago. Now a glass-and-aluminum apartment tower anchors the southern end of this scene, filling in a rare gap within this landmarked streetwall and putting a bow on the career of another heroic figure in Chicago’s architectural history: Helmut Jahn. Read the full story...
Reprinted courtesy of Mark Byrnes, Bloomberg

Behavioral Science Meets Construction: Insights from Whistle Rewards

September 09, 2024 — Aarni Heiskanen - AEC Business
In this episode of the AEC Business Podcast, Aarni Heiskanen hosts Drew Carter, CEO of Whistle Rewards, and Dr. Laurel Newman, a behavioral scientist, to discuss instant rewards for driving behavioral change in construction. Laurel shares her psychology background and academic career, studying how the environment influences behavior. Drew introduces himself as a data scientist, focusing on predictive modeling. Tune in to learn how they collaborate to create motivating environments in the construction industry. Whistle Rewards is a platform specializing in rewards, recognition, and incentives in the AEC industry. It is designed to enhance employee engagement, safety compliance, performance, and technology adoption in construction companies. The Guests Drew Carter, CEO and Co-Founder at Whistle Systems, Inc. Drew is improving employee retention using data science and behavioral science. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Quick Note: Staying, Not Dismissing, Arbitrable Disputes Under Federal Arbitration Act

July 31, 2024 — David Adelstein - Florida Construction Legal Updates
As you hopefully know from posted articles, arbitration is a creature of contract. Stated differently, there must be a contractual basis to have a dispute resolved through binding arbitration. The Federal Arbitration Act (FAA) applies to transactions involving interstate commerce. Oftentimes, lawsuits are filed despite an arbitration provision in a contract because parties can, if they desire, waive their rights to have their dispute resolved through binding arbitration. In what should not be a shocker, the United States Supreme Court in Smith v. Spizzirri, 144 S.Ct. 1173, 1178 (2024), held that when a federal “district court finds that a lawsuit involves an arbitrable dispute, and a party requests a stay pending arbitration, section 3 of the FAA compels the court to stay the proceeding.” Dismissing the lawsuit should not be the option. Staying the lawsuit should. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES