COLUMBUS OHIO BUILDING CONSULTANT
DIRECTORY AND CAPABILITIES

Is Safety Compliance Putting Your Project in Jeopardy? Examining the Essentials of DOE’s Worker Safety and Health Program

July 02, 2024 — Lucas T. Daniels & Benjamin J. Hochberg - ConsensusDocs
Most contractors are familiar with the myriad of labor and safety regulations intended to safeguard the health and safety of workers. Many contractors will be equally familiar with the maze of forms and reports, the maintenance of safety personnel, safety walks and talks, and the many other measures intended to prevent and prepare for accidents. Less known among contractors and construction industry leaders is the regulatory framework establishing safety requirements and the ramifications of ignoring safety-related rules. Knowing and understanding the jurisdiction and authority of the agencies monitoring safety compliance on your project is critical to avoiding administrative ordeals and audits that could add days or weeks to your schedule and frustrate your staff. The Department of Energy’s Worker Safety and Health Program Under the Occupational Safety and Health Act of 1970, as amended (OSH), the Department of Labor’s Occupational Safety and Health Administration (OSHA) issues and enforces occupational health and safety regulations. OSHA, or a state with approval from OSHA, regulates the occupational health and safety of private sector employees unless another federal agency has and exercises its statutory authority to regulate. Several federal agencies have developed their own safety programs and conduct their own enforcement of those regulations independent of OSHA. For example, projects receiving funding from the Department of Energy (DOE) are subject to additional oversight of their safety programs by this agency. DOE directly manages its own Worker Safety and Health Program (WSHP), codified at 10 C.F.R. § 851, et seq., and will enforce compliance with its WSHP at all DOE sites. A “DOE site” is defined as a DOE-owned or -leased area or location or other area or location that DOE controls, where a contractor performs activities and operations in furtherance of a DOE mission. This broad definition encompasses a wide range of facilities and operations, including those not directly managed by the DOE but still under its control. The contractor at such a site must be aware of the specific requirements and procedures of the DOE under the WSHP and the ramifications of violating these regulations. Reprinted courtesy of Lucas T. Daniels, Peckar & Abramson, P.C and Benjamin J. Hochberg, Peckar & Abramson, P.C Mr. Daniels may be contacted at ldaniels@pecklaw.com Mr. Hochberg may be contacted at bhochberg@pecklaw.com Read the full story...

---

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Bremer Whyte Sets New Precedent in Palos Verdes Landslide Litigation

August 26, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
In what is believed to be a groundbreaking new precedent, Bremer Whyte Brown & O’Meara’s Los Angeles litigation team has obtained a landmark ruling on behalf of residents in the “Portuguese Bend” neighborhood of Palos Verdes, California. Congratulations to Partner Michael D’Andrea and Senior Associate Shelly Mosallaei in receiving this result for our clients. Plaintiff, a real estate developer, sued a number of local residents and property owners, including our client, alleging that their failure to address landslides and geological disturbances around Plaintiff’s property constituted a legal trespass and nuisance. Plaintiff alleged that its plans to develop multiple lots in Palos Verdes was thwarted because Defendant’s soil and land encroached onto Plaintiff’s property. Plaintiff’s suit against multiple residents created an uproar in the community regarding who was ultimately responsible (if anyone) for natural soils movement that has plagued this neighborhood for years. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

---

When Licensing Lapses: How One Contractor Lost a $1 Million Dispute

October 28, 2024 — Matthew DeVries - Best Practices Construction Law
As a construction lawyer, contractor licensing is a very key aspect of my practice. This can include new contractor applications, increase or changes in monetary limits or license classifications, change in ownership or qualifying agent , and, of course, licensing violations. The recent decision in Incident365 Florida, LLC v. Ocean Pointe V Condominium Association serves as an important reminder for general contractors and subcontractors regarding the significance of proper licensing and thorough contract review in disaster recovery and construction services. Case Overview In this case, Incident365 Florida, LLC entered into disaster recovery agreements with several condominium associations (“Associations”) following Hurricane Irma. The agreements involved various tasks such as water damage mitigation, dehumidification, and the removal of unsalvageable materials. However, Incident365 lacked the appropriate contractor’s license when performing the work, which became a focal point in the dispute when the Associations refused to pay the remaining balance of $1 million, citing the absence of the required licensure. Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

---

Newport Beach Partners Jeremy Johnson, Courtney Serrato, and Associate Joseph Real Prevailed on a Demurrer in a Highly Publicized Shooting Case!

November 11, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara’s Partners Jeremy Johnson, Courtney Serrato, and Associate Joseph Real prevailed on a Demurrer in a highly publicized shooting case. Plaintiffs filed a lawsuit alleging negligence, negligent hiring, supervision and retention, and public nuisance against BWB&O’s clients, a highly recognized hospitality and lifestyle company with nightlife and restaurant venues, in addition to other celebrity defendants. Plaintiffs were the victims of a shooting that occurred by an unknown individual(s) outside and near the restaurant/venue owned by BWB&O’s clients. Plaintiffs alleged it was BWB&O’s clients that were responsible for the third parties’ criminal acts because BWB&O’s clients attracted more people than the venue’s capacity, causing people to occupy the street, sidewalk, and property nearby. Plaintiffs further alleged that BWB&O’s client should have anticipated or known that criminal conduct, including gun violence, would take place. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

---

Why Being Climate ‘Positive’ Is the Buzzy New Goal of Green Building

December 10, 2024 — Olivia Rudgard - Bloomberg
The three buildings, dotted around Norway, couldn’t look more different: a soaring timber-and-concrete obelisk in Porsgrunn; a squat, two-story Montessori school on the edge of a forest in Drøbak; and a concrete and glass wedge-shaped office in Trondheim, just a few hundred miles from the edge of the Arctic Circle. But they share a distinctive feature. Each has a roof perfectly tilted to squeeze out every possible drop of solar energy. They are called Powerhouses, and the initiative behind them claims they are all “energy positive”: The upfront energy “cost” of each building, and that of later demolition and disposal, is expected to be made back over the building’s lifetime. Powerhouses sometimes draw from the grid, especially in winter, but in the long Nordic summer days they give back many times over, overspilling excess solar energy into surrounding homes and businesses. Read the full story...
Reprinted courtesy of Olivia Rudgard, Bloomberg

---

San Francisco Office Secures Defense Verdict in Legal Malpractice Action

November 25, 2024 — Lewis Brisbois Newsroom
San Francisco, Calif. (October 31, 2024) - After a ten-day jury trial in San Francisco Superior Court, Partner Alex Graft recently secured a defense verdict in a legal malpractice action arising out of underlying litigation with the claimants’ homeowners association. The claimants alleged his client attorneys negligently advised them that the terms of the settlement agreement would result in the creation of a so-called independent board of directors for the homeowners association. It did not come to fruition. After the attorneys withdrew, they sued for their outstanding fees, which elicited a cross-complaint alleging malpractice, breach of fiduciary duty, breach of contract and negligent misrepresentation. Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Nomos LLP Partner Garret Murai Recognized by Super Lawyers

July 08, 2024 — Garret Murai - California Construction Law Blog
Nomos LLP Partner Garret Murai has been recognized as a 2024 Northern California Super Lawyers honoree in the area of Construction Litigation. This is the eleventh consecutive year that he has been recognized by Super Lawyers. Super Lawyers, an annual listing of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and personal achievement, is limited to no more than five percent (5%) of lawyers in a state who are selected through a multiphase process that includes a statewide survey of lawyers, independent research evaluation and peer reviews by practice area. Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---