ANAHEIM CALIFORNIA BUILDING CONSULTANT
DIRECTORY AND CAPABILITIES

Five Issues to Consider in Government Contracting (Or Any Contracting!)

September 02, 2024 — David Adelstein - Florida Construction Legal Updates
The appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting. Issue #1- Patently Ambiguous Specifications The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Newport Beach Partners Jeremy Johnson, Courtney Serrato, and Associate Joseph Real Prevailed on a Demurrer in a Highly Publicized Shooting Case!

November 11, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara’s Partners Jeremy Johnson, Courtney Serrato, and Associate Joseph Real prevailed on a Demurrer in a highly publicized shooting case. Plaintiffs filed a lawsuit alleging negligence, negligent hiring, supervision and retention, and public nuisance against BWB&O’s clients, a highly recognized hospitality and lifestyle company with nightlife and restaurant venues, in addition to other celebrity defendants. Plaintiffs were the victims of a shooting that occurred by an unknown individual(s) outside and near the restaurant/venue owned by BWB&O’s clients. Plaintiffs alleged it was BWB&O’s clients that were responsible for the third parties’ criminal acts because BWB&O’s clients attracted more people than the venue’s capacity, causing people to occupy the street, sidewalk, and property nearby. Plaintiffs further alleged that BWB&O’s client should have anticipated or known that criminal conduct, including gun violence, would take place. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

---

Understanding Entitlement to Delays and Proper Support

December 10, 2024 — Andrew G. Vicknair - The Dispute Resolver
In a previous post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method. Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay. If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

Preserving Lien Rights on Private Projects in Washington: Three Common Mistakes to Avoid

September 16, 2024 — Kristina Southwell - Ahlers Cressman & Sleight PLLC
The Washington Construction Lien Statute, RCW 60.04 et seq., exists to help secure payment for work performed for the improvement of real property.[1] The statute grants “any person furnishing labor, professional services, materials, or equipment for the improvement of real property” the authority to claim “a lien upon the improvement for the contract price of labor, professional services, materials, or equipment furnished.” RCW 60.04.021. Exercising lien rights is one of the most useful tools available to a contractor or supplier trying to recover payment owed on a project. A properly recorded lien binds the project property, which is typically the most valuable asset held by the owner, as security for the amounts owed to the lien claimant. Additionally, the lien statute provides a basis for the claimant to recover the costs of recording the lien and its attorneys’ fees and expenses incurred in litigating the foreclosure of the lien. While the lien statute authorizes the right to lien, it also provides a series of strict requirements and procedures that a claimant must follow to properly exercise its rights. The claimant must carefully comply with all statutory requirements. This article does not endeavor to explain all the intricacies of the lien statute, but rather discusses three of the most common mistakes that result in the loss of lien rights. See our lien and bond claim manual for a more detailed guide to construction liens in Washington. Read the full story...
Reprinted courtesy of Kristina Southwell, Ahlers Cressman & Sleight PLLC
Ms. Southwell may be contacted at kristina.southwell@acslawyers.com

---

Anatomy of a Data Center

October 28, 2024 — Robert A. James & Matt Olhausen - Gravel2Gavel Construction & Real Estate Law Blog
Traditional and social media are thick with reports and predictions of the remarkable increase in size, power consumption and significance of data centers. Not only technology companies but real estate and energy developers, investment funds, lenders, and professionals of all stripes are in or determined to enter this sector. Our inboxes are full—it’s data center this, data center that. But what exactly is a data center? What infrastructure, technology and human resources come together to create and sustain one of these localized points of computation? By understanding their components, we can glean some understanding of the business, public policy and (our focus) legal issues that arise before and during their operation. In this article, we cite key characteristics of a reference Blackacre Data Center, with occasional glances at other (real) structures that offer variations on themes. Blackacre is a composite of several centers we have encountered in our law practice. These facilities differ widely in size, location and functions, so your mileage will vary. Reprinted courtesy of Robert A. James, Pillsbury and Matt Olhausen, Pillsbury Mr. James may be contacted at rob.james@pillsburylaw.com Mr. Olhausen may be contacted at matt.olhausen@pillsburylaw.com Read the full story...

---

Athletic Trainers Help Workers Get Back to the Jobsite and Stay Healthy After Injury

August 12, 2024 — Bryan Lockhart - Construction Executive
There are a number of factors on an active jobsite that can lead to workplace injuries. Heavy machinery, fast-moving equipment, material handling, loud noises and more can create safety hazards and make it easy to lose focus or become distracted. Additionally, the movements workers have to do in their roles—such as lifting or pushing objects or crouching low to the ground for extended periods—can add strain to the body if not done correctly. The goal is always to minimize the risk of injury, and yet, incidents still occur. According to 2020 Bureau of Labor Statistics data, slips, trips and falls are the most common injuries, accounting for 18% of non-fatal work injuries resulting in days away from work. When workers are injured, it can lead to downtime, lost productivity on the site and workers’ compensation claims. Employers and site leaders can take various approaches to help workers return to the jobsite safely and effectively and keep them healthy once they return. Introducing an onsite clinic and athletic trainers can help prevent injuries, improve worker health, get people back to work effectively and keep them healthy in the long run. Here are three ways athletic trainers help workers get back to the job and improve their overall health. Reprinted courtesy of Bryan Lockhart, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

First Circuit Finds No Coverage For Subcontracted Faulty Work

December 17, 2024 — Eric Hermanson & Austin Moody - White and Williams LLP
After almost two years' deliberation, the First Circuit last week issued its long-awaited decision in Admiral Ins. Co. v. Tocci Bldg. Corp.[1]: affirming on other grounds, and leaving in place a district court decision that found subcontracted faulty work was not an "occurrence" and did not lead to covered “property damage” under Massachusetts law. The decision leaves Massachusetts among a number of states where general contractors should not expect coverage from their commercial general liability (CGL) insurers for damage falling within the contractor’s scope of work. Since the "scope of work" – where general contractors are involved – often encompasses an entire project, contractors who want coverage in Massachusetts should take care to make alternative arrangements: transferring risk to subcontractors through indemnity provisions and additional-insured endorsements, or relying on other policy forms where available. Reprinted courtesy of Eric Hermanson, White and Williams LLP and Austin Moody, White and Williams LLP Mr. Hermanson may be contacted at hermansone@whiteandwilliams.com Mr. Moody may be contacted at moodya@whiteandwilliams.com Read the full story...

---

Seattle Developer Defaults on Renovated Office Buildings

December 23, 2024 — Anna Edgerton - Bloomberg
A major developer in downtown Seattle defaulted on a loan backed by two of its most prized office properties, including one that formerly housed a branch of the Federal Reserve Bank of San Francisco. Firms tied to Martin Selig Real Estate are in default on a more than $200 million loan, according to letters from lender Acore Capital dated Nov. 15 that were filed in Washington’s King County. The buildings would change ownership 30 days after that notice if no other action is taken, according to the letters. Read the full story...
Reprinted courtesy of Anna Edgerton, Bloomberg

---