ANAHEIM CALIFORNIA BUILDING CONSULTANT
DIRECTORY AND CAPABILITIES

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Providence Partner Monica R. Nelson Helps Union Carbide Secure Defense Verdict in 1st Rhode Island Asbestos Trial in Nearly 40 Years

December 31, 2024 — Lewis Brisbois Newsroom
Providence, R.I. (November 22, 2024) - On November 21, 2024, a Providence County jury returned a unanimous defense verdict for Union Carbide Corporation after a nine-day trial presided over by Associate Justice Richard A. Licht. Tim McGowan of Kelley Jasons McGowan Spinelli Hanna & Reber LLP, Eric Cook of Willcox Savage, and Monica R. Nelson of Lewis Brisbois Bisgaard & Smith LLP represented Union Carbide at trial. Elliott Davis of Shook Hardy & Bacon was Union Carbide’s appellate counsel. The plaintiffs’ lawyers, Vincent L. Greene IV, Nathan D. Finch, and Ashley Hornstein of Motley Rice LLC, represented the family of Mrs. Bonnie Bonito in the first asbestos matter to go to trial in Rhode Island in close to 40 years and requested nearly $25 million in compensatory damages for the death of Mrs. Bonito from her alleged exposure to Union Carbide’s asbestos, among many other asbestos-containing products, through the work clothes of her husband. The plaintiffs’ proffered theory of liability against Union Carbide Corporation is known as a “take-home” exposure claim. Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Beyond the Flow-Down Clause: Subcontract Provisions That Can Expose General Contractors to Increased Liability and Inconsistent Outcomes

December 10, 2024 — Phillip L. Parham III - ConsensusDocs
Flow-down clauses in construction subcontracts—blanket clauses providing that some or all of the terms and conditions in the prime contract between the general contractor and the property owner apply equally between the subcontractor and general contractor—are an important component to managing risk for a general contractor and reducing the likelihood of disputes with either/both the owner and subcontractor. Put simply, flow-down provisions can provide continuity between the general contractor’s obligations to the owner and the subcontractor’s obligations to the general contractor. Properly drafted, flow-down clauses reduce the general contractor’s risk by ensuring that the subcontractor is legally bound to meet the owner’s objectives for the project in the same way as the general contractor. But relying on blanket flow-down clauses, alone, to protect the general contractor is like a soldier going into battle with nothing but a helmet, leaving significant other areas exposed and unprotected. In other words, a general contractor should look beyond just a singular, blanket flow down of terms to ensure its bases are properly covered. Accordingly, this article goes beyond the blanket flow-down clause and highlights several key subcontract provisions where inconsistent obligations among the subcontractor, general contractor, and owner expose the general contractor to increased liability and inconsistent outcomes. Specifically, this article will examine disputes resolution clauses, liquidating provisions, notice provisions, and termination provisions. However, this article will not provide a deep examination of these clauses, nor does it highlight every potentially relevant clause. Rather, it focuses on these select clauses to highlight important issues associated with flow-down provisions. Read the full story...
Reprinted courtesy of Phillip L. Parham III, Jones Walker LLP
Mr. Parham may be contacted at pparham@joneswalker.com

---

Governor Bob Ferguson’s Recent Executive Orders – A Positive Sign for Washington’s Construction Industry

January 21, 2025 — Ryan Sternoff & Trygve Groh - Ahlers Cressman & Sleight
On January 15th, in his first act as Washington’s Governor, Bob Ferguson signed three executive orders, two of which may have a direct impact by removing some of the “red tape” that stifles Washington’s construction industry. This appears to be a positive sign that the Governor’s office is focused on pragmatic action, rather than partisan politics. Executive Order 25-02 is entitled “Assessing Regulatory Efficiency and Addressing Washington’s Affordable Housing Crisis” and directs all executive and small cabinet agencies (collectively, “State Agencies”) to review their rules and regulations and prepare a report for the Governor’s Office that identifies rules or regulations that impact the construction of new housing. The reports will also identify rules or regulations that are no longer necessary and can be rescinded, rules or regulations that can be amended to speed up housing construction. The reports will include descriptions of proposed amendments to such rules and regulations. The reports must be provided to the Governor’s Office within sixty days. Read the full story...
Reprinted courtesy of Ryan Sternoff, Ahlers Cressman & Sleight
Mr. Sternoff may be contacted at ryan.sternoff@acslawyers.com

---

Understanding Insurance Disputes in Construction Defect Litigation: A Review of Acuity v. Kinsale

December 17, 2024 — David M. McLain – Colorado Construction Litigation Blog
Construction projects are inherently complex, and insurance coverage plays a crucial role in managing risks, especially when unforeseen issues arise. The case of Acuity v. Kinsale demonstrates the tangled web of insurance obligations, especially when multiple insurers provide coverage for a single event. This case, involving Monarch Stucco, Inc., Acuity, and Kinsale Insurance Company, sheds light on the challenges that contractors, subcontractors, and insurers may face when disputes over liability and coverage occur. The Background of the Case At the heart of this dispute lies a construction defect at a retirement community project in Lakewood, Colorado. Monarch Stucco, Inc. (“Monarch”), a subcontractor hired by GH Phipps Construction Company (“Phipps”), was responsible for stucco work on the project. Unfortunately, defects in the building’s envelope system, particularly Monarch’s stucco work, led to significant damage and costly repairs. Read the full story...
Reprinted courtesy of David M. McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

---

Sources of Insurance Recovery for Emerging PFAS Claims

December 17, 2024 — Jasjeet K. Sahani - Saxe Doernberger & Vita, P.C.
This year, the Environmental Protection Agency (“EPA”) issued its first-ever national, legally enforceable drinking water standard to protect communities from exposure to harmful per-and polyfluoroalkyl substances (“PFAS”), also known as “forever chemicals.”[1] In addition, the Food and Drug Administration announced that grease-proofing materials containing PFAS are no longer being sold for use in food packaging in the United States.[2] These are likely the first in a line of many PFAS regulations that will emerge as the harmful effects of PFAS are further understood. With this increasing regulatory focus on PFAS and their harmful effects, companies whose operations might involve these substances should be aware of what they are and potential sources of recovery for claims that arise from their omnipresence. PFAS Background According to the EPA, PFAS are widely used, long-lasting chemicals which break down slowly over time.[3] PFAS can be found in thousands of items, including, but not limited to: pots and pans, cleaning products, fabric and leather coatings, firefighting foam, carpeting, roofing materials, paints, sealants, caulks, and adhesives.[4] Additionally, manufacturing processes, waste storage, and treatment sites commonly release PFAS into the air, soil, and water.[5] Read the full story...
Reprinted courtesy of Jasjeet K. Sahani, Saxe Doernberger & Vita, P.C.
Ms. Sahani may be contacted at JSahani@sdvlaw.com

---

A Game of Texas Hold’em: How Texas Stopped Wage Increases for Salaried Exempt Employees Nationwide

December 03, 2024 — Matthew DeVries - Best Practices Construction Law
Construction contractors often have to deal with classification of employees, particularly those who work in the home office. Today’s guest post by Alexandra Shulman and Leah Lively addresses a recent court decision affecting the wage protection of employees under the the Fair Labor Standards Act (FLSA). On November 15, 2024, a federal court in Texas vacated a U.S. Department of Labor (DOL) rule (the “2024 Rule”) that increased the minimum salary threshold for employees classified as exempt from overtime and minimum wage protections under the FLSA. The Texas court’s decision nullifies the 2024 Rule nationwide, effective immediately. Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

---

New Mexico Holds One-Sided Dispute Resolution Provisions Are Unenforceable

November 05, 2024 — Bill Wilson - Construction Law Zone
Dispute resolution provisions that grant one party the unilateral right to choose either litigation or arbitration to resolve disputes are common in the construction industry. The main difference between the two forums is that courts are more likely to strictly enforce contract terms as written as well as the applicable law, while arbitrators make decisions on more equitable considerations, untethered to the contract terms and—to some degree—the law. The party with the sole discretion to select the dispute resolution procedure can select the process most beneficial to its interests based on the nature of the dispute, regardless of who brings the claims. In Atlas Electrical Construction, Inc. v. Flintco, LLC, 550 P.3d 881 (N.M. Ct. App. 2024), the Court of Appeals of New Mexico recently held that an arbitration provision in a subcontract, under which the contractor retained the exclusive right to choose whether disputes arising under the subcontract were litigated in court or arbitrated was unreasonably one-sided, substantively unconscionable, and unenforceable. The Atlas Electrical case involved two sophisticated entities with equal bargaining strength to negotiate the terms of a subcontract. The parties agreed to a subcontract provision which provided in the relevant part:

In the event [contractor] and [subcontractor] cannot resolve the dispute through direct discussions or mediation … then the dispute shall, at the sole discretion of [contractor], be decided either by submission to (a) arbitration … or (b) litigation …

Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

---