ANAHEIM CALIFORNIA BUILDING CONSULTANT
DIRECTORY AND CAPABILITIES

Word of the Day: “Contractor”

September 16, 2024 — Garret Murai - California Construction Law Blog
What’s in a word? When it comes to insurance policies, a word, can potentially mean millions of dollars. In California Specialty Insulation, Inc. v. Allied World Surplus Lines Insurance Company, 102 Cal.App.5th 1 (2024), an insured and its insurer battled it out over the word “contractor,” and whether an exclusion from coverage of bodily injury to any employee or temporary worker “of any contractor or subcontractor,” excluded a personal injury claim brought by an employee of a general contractor against a subcontractor. The California Specialty Contractor Case In 2017, Air Control Systems, Inc. (“Air Control”) was contracted to perform improvements at a building in Los Angeles, California. Air Control in turn subcontracted with California Specialty Insulation, Inc. (“CSI”) to install duct insulation on the project. During construction, an employee of Air Control was injured when he fell 16 to 20 feet from a ladder that was struck by a scissor lift driven by an employee of CSI. Approximately two years later the Air Control employee filed a personal injury lawsuit against CSI. Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

Five Issues to Consider in Government Contracting (Or Any Contracting!)

September 02, 2024 — David Adelstein - Florida Construction Legal Updates
The appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting. Issue #1- Patently Ambiguous Specifications The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Construction Defect Disputes: Know Your Measure of Damages!!!!!

January 21, 2025 — David Adelstein - Florida Construction Legal Updates
Remember this: know your measure of damages in a construction defect dispute. If you don’t, as shown below, the outcome can be unforgiving. The measure of damages is one of your most important elements of proof. You are filing suit for damages; thus, knowing what you can reasonably recovery is paramount. In a recent dispute, Bandklayder Development, LLC v. Sabga, 50 Fla.L.Weekly D91e (Fla. 3d DCA 2025), a residential developer sold a single-family house while it was under construction in an as-is purchase agreement. Post-closing, the purchasers claimed defects and served a Florida Statutes Chapter 558 notice of construction defects letter. The purchaser subsequently initiated a construction defect lawsuit. During the nonjury trial, the purchaser’s expert testified that the purchasers suffered damages approximating $323,000 calculated as of January 19, 2022 (which was the date of the expert’s report). The expert further testified that the cost to finish the incomplete/defective work increased by 35% at the date of the May 2023 trial. However, the expert never testified as to the amount of damages as of the date of the contractual breach, which at the latest, would have been in April 2018 when the notice of construction defects letter was sent (or, at its earliest, June 2017 when closing occurred). At trial, the judge entered judgment for the purchasers in the amount of about $425,0000. This was reversed on appeal with judgment to be entered in favor of the developer. Why? Because the purchasers employed the wrong measure of damages and the only thing that prevented them from introducing the right measure of damages was within their control. Harsh outcome for not applying the correct measure of damages! Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Snooze You Lose? Enforcement of Notice and Timing Provisions

November 11, 2024 — Cornelius F. "Lee" Banta, Jr. - ConsensusDocs
Deadlines are an inescapable part of the construction industry. Bid deadlines. Submittal deadlines. Material delivery deadlines. Substantial completion. Final completion. And so, inevitably, fighting about deadlines becomes a necessary byproduct. Was the deadline really a deadline? Was the schedule slippage on the critical path? Should there be an equitable extension to the date of substantial completion? Given the amount of attention and concern conferred on deadlines, those drafting construction contracts naturally seek to clarify which deadlines really matter with the inclusion of notice and timing provisions. A contract’s change order and claims procedures are often a key friction point for those drafting and administering the contract. Should there be a requirement for prior written notice of a claim for cost/time relief? How much advance notice? Who should the request be sent to? Is a specific form of notice required? What are the consequences of failing to provide timely notice? A practitioner should pay careful attention to negotiating these terms on the front end, because rest assured, these contract provisions will garner scrutiny when a change order dispute boils over. Read the full story...
Reprinted courtesy of Cornelius F. "Lee" Banta, Jr., Peckar & Abramson, P.C.
Mr. Banta may be contacted at lbanta@pecklaw.com

---

Owners and Contractors are Liable for Injuries Caused by their Independent Contractors under the “Peculiar Risk Doctrine”

October 15, 2024 — William L. Porter - Porter Law Group
Many contractors and owners believe that if they hire an independent contractor to perform work and that independent contractor causes injury to others during the performance of that work, then it is the independent contractor alone who will be liable for those injuries. In most circumstances, this is correct. The owner or the contractor will not be held liable for injuries caused by his or her independent contractor. However, this is not always the case. Under the “Peculiar Risk Doctrine” and California cases interpreting the doctrine, a contractor or owner who hires an independent contractor to do work which is considered to be “inherently dangerous work” can be still be held directly liable for damages when that independent contractor causes injury to others by negligently performing the work. Such liability can generally be imposed on the one hiring the independent contractor under either of two branches of the peculiar risk doctrine. First, where a person hires an independent contractor to do inherently dangerous work, but fails to provide in the contract or in some other manner that special precautions must be taken to avert the peculiar risk of injury related to that work, then the one hiring the independent contractor can be held liable for injuries to others caused by the independent contractor’s negligence. (Restatement Second of Torts Section 413). For example, in Mackey v. Campbell Construction Co. 101 Cal. App. 3d 774, 162 Cal. Rptr. 64 (1980), Western Electric Company, the owner of the project, was found liable for the personal injuries of a subcontractor’s employee because Western’s representatives were on the job at all times, had doubts about the safety of scaffolding being used on the project, yet failed to require use of precautions that could have been taken to avoid injury. Read the full story...
Reprinted courtesy of William L. Porter, Porter Law Group
Mr. Porter may be contacted at bporter@porterlaw.com

---

Rejection’s a Bear- Particularly in Construction

December 23, 2024 — Christopher G. Hill - Construction Law Musings
As I read through this week’s cases published in Virginia Lawyers Weekly, I came across a case posing an interesting question. The question is, “If your bid is rejected along with everyone else’s, can you complain?” The short answer set out by the Rockingham County, Virginia Circuit Court is “No.” In the case of General Excavation v. City of Harrisonburg the Court looked at the Virginia Public Procurement Act’s bid protest provisions in Va. Code 2.2-4360 and 2.2-4364(C) in the context of General Excavation’s protest of the City’s failure to award it (or anyone else for that matter) the contract on which it was the low bidder. The controlling section of the statute allows a challenge to the award or proposed award of a contract. In defending the action, the City of Harrisonburg argued that, because the Procurement Act waived some of the city’s sovereign immunity, it must be read strictly. The city further argued (somewhat ironically) that, because no award of the contract was given or even proposed, General Excavation could not bring suit because it would not be challenging the “proposed award or award” of a contract. Not surprisingly, the Rockingham County court held with the City and strictly construed the statute against General Excavation in finding that General Excavation did not have the standing necessary to bring suit under the statute. Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Definitions Matter in Illinois: Tenant Held Liable Only for Damage to Apartment Unit

September 09, 2024 — Gus Sara - The Subrogation Strategist
In Phila. Indem. Ins. Co. v. Gonzalez, No. 1-23-0833, 2024 Ill. App. Unpub. LEXIS 1372, the Appellate Court of Illinois considered whether the terms of a lease agreement limited a tenant’s liability for fire damages, a fire caused by her negligence, to her apartment unit only. The plaintiff insured the subject apartment building, which incurred damage to several units as result of a fire in the tenant’s unit. The lease defined “Premises” as the specific apartment unit occupied by the tenant and held the tenant responsible for damage caused to the Premises. While the court found that the lease permitted the plaintiff to subrogate against the tenant, it held that the lease terms limited the damages to the tenant’s apartment unit only. In Gonzalez, the plaintiff’s insured owned a multi-unit apartment building in Chicago. In September 2019, the building owner entered into a lease agreement with the defendant for apartment Unit 601. The lease stated that Unit 601 was the “Leased Address (Premises).” Another provision stated that building owner “hereby leases to Tenant(s) and Tenant(s) hereby leases from Landlord(s) for use as a private dwelling only, the Premises, together with the fixtures and appliances (if any) in the premises…” The lease also stated that “Tenant shall be liable for any damage done to the premises as a result of Tenant’s or Tenant’s invitees, guests or others authorized to reside in the Premises [sic] direct action, negligence, or failure to inform Landlord of repairs necessary to prevent damage to the Premises.” Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

---

Benefit of the Coblentz Agreement and Consent Judgment

August 26, 2024 — David Adelstein - Florida Construction Legal Updates
If you are not familiar with the concept of what is commonly known as a Coblentz agreement relative to an insurance coverage dispute, review these prior postings (here and here and here). This is a good-to-know agreement if you are a claimant and need to consider an avenue of collection if the insured’s carrier denies coverage out of the gate (meaning the carrier has denied both the duty to defend and the duty to indemnify). A recent Eleventh Circuit Court of Appeals opinion demonstrates the Coblentz agreement concept. In Barrs v. Auto-Owners Ins. Co., 2024 WL 3673089 (11th Cir. 2024), an owner asserted a construction defect claim against its contractor. The owner hired the contractor to deconstruct a building and the contractor hired a demolition subcontractor. The owner noticed work was not being performed and materials (e.g., lumber) were missing; the demolition subcontractor had stolen materials. The subcontractor was terminated, and the owner claimed the contractor’s negligence allowed the theft and delayed his project. The contractor’s commercial general liability (CGL) insurer notified the insured-contractor that coverage did not exist and refused to defend the contractor. The owner sued the contractor under various theories of liability. The owner and contractor entered into a settlement agreement (i.e., the Coblentz agreement) where the contractor “admitted liability in the amount of $557,500.00….A consent judgment was entered against [the contractor] that closely tracked the settlement agreement but did not indicate which portion of the damages award was attributed to which claims. The agreement also assigned [owner] and all of [the contractor’s] rights to claim coverage and to recover available funds under [the contractor’s CGL policy].” Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---