Anaheim California Building Consultant Directory

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Real Estate & Construction News Roundup (7/2/24) – Increase in Commercial Property Vacancy Rates, Trouble for the Real Estate Market and Real Estate as a Long-Term Investment

July 31, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, the evolution of stadium construction, an increase in legal and legislative action affecting the multifamily sector, and growing concerns for owners of office space.

The work-from-home trend will likely push up the commercial property vacancy rate in 2026 to a peak average of 24%, or 4 percentage points higher than the first quarter of this year. (Jim Tyson, CFO Dive)
In recent years, stadium construction has evolved to focus more on cultivating the game day experience with some multibillion-dollar projects breaking ground, as existing venues get renovations. (Zachary Phillips, Construction Dive)
A number of prominent issues affecting the multifamily industry, including rent control, fees and antitrust concerns, have been subject to increasing levels of legal and legislative action over the past year. (Mary Salmonsen, Multifamily Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Arizona Court Affirms Homeowners’ Association’s Right to Sue Over Construction Defects

October 15, 2024 — Melissa Kenney - White and Williams LLP
In Gallery Community Association v. K. Hovnanian at Gallery LLC, No. 1 CA-CV 23-0375, 2024 Ariz. App. Unpub. LEXIS 696 (Ct. App.), the Court of Appeals of Arizona (Court of Appeals) discussed whether a homeowners’ association can file an action for breach of the implied warranty of workmanship and habitability arising from construction defects. At issue was whether the implied warranty extended to the areas within the community that the association maintained, including the common areas. The Court of Appeals held that homeowners’ associations can sue builder-vendors for breach of the implied warranty arising from construction defects. In this case, a homeowners’ association, responsible for managing and maintaining a community of townhomes, sued the developer/builder for alleged construction defects in the common area and exteriors of homes that the association maintained for the homeowners in the community. The alleged defects included the pool cabana and staircase walls in the common areas and the exterior walls, roofs, and staircases on the separately owned townhomes in the community. The builder filed a motion for summary judgment, arguing that the implied warranty extended to dwelling actions initiated by homeowners – not homeowners’ associations – and that the alleged construction defects at issue were not related to a dwelling. The trial court granted the motion. The Court of Appeals vacated the trial court’s grant of summary judgment and remanded for further proceedings. In reaching its decision, the Court of Appeals determined that both common law and statutory law authorized the homeowners’ association’s breach of implied warranty claim. Read the full story...
Reprinted courtesy of Melissa Kenney, White and Williams
Ms. Kenney may be contacted at kenneyme@whiteandwilliams.com

Federal Court Holds that Demolition Exclusion Does Not Apply and Carrier Has Duty to Defend Additional Insureds

September 02, 2024 — Craig Rokuson - Traub Lieberman
In the recent case of Travelers Indem. Co. v. Trisura Specialty Ins. Co., 2024 U.S. Dist. LEXIS 101953 (S.D.N.Y. June 7, 2024), the court had occasion to consider the classic additional insured fact pattern of a construction accident. Travelers insured the general contractor and provided a defense to the general contractor as well as its wholly owned subsidiary. Trisura insured the subcontractor, who employed the injured worker. Travelers brought suit, alleging that Trisura is obligated to defend and indemnify the general contractor, its subsidiary, the owner of the building (The City of New York), and the tenant. Trisura denied any obligation to provide coverage due to the application of the “Demolition Exclusion” to the Trisura policy, which provides, in part, that there is no coverage for injury or damage arising out of the demolition of any building or structure which has original ground height in excess of three stories. The accident occurred during the interior demolition of the fifth floor of the building. The court held that the Demolition Exclusion applies only when there is a complete tearing down, razing, or destruction of an entire building. As the accident occurred during interior demolition, the exclusion did not apply. Read the full story...
Reprinted courtesy of Craig Rokuson, Traub Lieberman
Mr. Rokuson may be contacted at crokuson@tlsslaw.com

Real Estate & Construction News Roundup (7/10/24) – Strong Construction Investment in Data Centers, Increase Use of Proptech in Hospitality and Effects of Remote-Work on Housing Market

August 05, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, renters stay in their units longer, GenAI change how commercial real estate operates, and banks continue high exposure due to commercial real estate.

Strong investor interest, particularly in opportunistic and value-add segments, signals a strong market for construction firms specializing in high-yield projects. (Sebastian Obando, Construction Dive)
A growing number of renters are staying in their units for longer periods of time than they did a decade ago with over one-third of U.S. renters have lived in the same apartment for more than five years. (Mary Salmonsen, Multifamily Dive)
Several U.S. regional and mid-sized banks continue to face the squeeze from high exposure to the commercial real estate sector that has been shaken by higher-for-longer interest rates and empty office buildings. (Reuters)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

ASCE Statement on Devastating Impacts of Hurricane Helene

October 07, 2024 — Marsia Geldert-Murphey, P.E., President - American Society of Civil Engineers
WASHINGTON, DC. – We are deeply saddened by the tragic loss of life across six states, in addition to the immeasurable damages caused by Hurricane Helene throughout the Southeast this past week. Hundreds of communities are without power. Citizens cannot move safely from one place to another. And in its wake, the storm has left many without drinking water and sewage services. As civil engineers, our first priority when we design and build the structures that connect us is the public's safety and well-being; we are heartbroken to see so many lives lost or upended by Hurricane Helene. As someone who has experienced losing everything in a catastrophic flood event, I have seen first-hand the need for making communities more resilient, and the consequences of failing to do so. Although hurricanes have consistently been a threat in the U.S., particularly in the Southeast, extreme weather events and 500-year floods are increasing in regularity and our aging infrastructure systems were not built to withstand storms of this magnitude. Total prevention of loss of life or property damage can never be guaranteed, but Helene is a reminder of the importance of widespread adoption of up-to-date, modern building codes and standards. We are thankful for the hard work of first responders, the military, and other organizations working around the clock to save lives and meet the immediate needs of people affected by this storm. As communities begin the long recovery process, civil engineers will be there to help communities rebuild the roads, bridges, dams, water systems, and other infrastructure damaged or destroyed by the storm. ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS Founded in 1852, the American Society of Civil Engineers represents more than 160,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel.

Kahana Feld Partner Noelle Natoli Named President of Women Lawyers Association of Los Angeles

October 07, 2024 — Linda Carter - Kahana Feld
LOS ANGELES – Sep. 16, 2024 – Kahana Feld is pleased to announce that partner Noelle Natoli was recently installed as the 2024-25 president of the Women Lawyers Association of Los Angeles (WLALA). The mission of WLALA is to promote the full participation in the legal profession of women lawyers and judges from diverse perspectives and backgrounds, maintain the integrity of our legal system by advocating principles of fairness and equality, and improve the status of women by supporting their exercise of equal rights. Natoli is a partner based in Kahana Feld’s Los Angeles office and focuses her civil trial practice on the defense of both insurers and insureds primarily in the areas of elder abuse, transportation defense, and general liability. Her clients include individuals, family-owned businesses, and national corporations. Natoli also chairs the Diversity & Inclusion Committee for the Trucking Industry Defense Association and serves as a board member of the National Conference of Women’s Bar Associations. Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

“Over? Did you say ‘over’?”

December 31, 2024 — Daniel Lund III - Lexology
The United States Seventh Circuit Court of Appeals recently held that under the Federal Arbitration Act, an arbitrator – and not a court – is to determine the preclusive effect of an arbitrator’s earlier ruling. In the case, insurers engaged in three reinsurance agreements had previously arbitrated concerning one of the insurer’s billing methodologies. When a similar dispute occurred years later, the victors in the first arbitration – rather than pursuing arbitration – filed in federal court in Chicago seeking to have the court declare that the prior arbitration award precluded re-arbitration of the latest dispute. The insurer on the other side of the dispute moved to compel arbitration, a motion granted by the district court. The plaintiff insurers appealed. Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES