Anaheim California Building Consultant Directory

Colorado Court of Appeals’ Ruling Highlights Dangers of Excessive Public Works Claims

August 26, 2024 — David M. McLain – Colorado Construction Litigation
In the case of Ralph L. Wadsworth Construction Company, LLC v. Regional Rail Partners (2024 COA 78), the Colorado Court of Appeals reviewed a complex contract dispute related to the design and construction of a transit rail line. The project, commissioned by the Regional Transportation District (“RTD”), involved a collaboration between Regional Rail Partners and Ralph L. Wadsworth Construction Company (“Wadsworth”) to build the North Metro Rail Line between Denver Union Station and Thornton. Key Facts:

Contracts and Payments: Regional Rail Partners contracted with Wadsworth to perform specific construction tasks with a total contract value of $60,210,783. By the time of the trial, Regional Rail had paid almost $58 million of this amount.
Disputes and Delays: The project faced numerous delays and disputes, leading to Wadsworth claiming significant financial damages attributed to these disruptions. In April 2018, Wadsworth’s expert estimated that Regional Rail owed them $12,408,496.60.

Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

An Overview of the New EPA HVAC Refrigerant Regulations and Its Implications for the Construction Industry

September 30, 2024 — Stefanie A. Salomon, Nadia Ennaji & Ali Heyat - Peckar & Abramson, P.C.
The U.S. Environmental Protection Agency (EPA) recently announced a series of significant changes to the rules governing the use of refrigerants in heating, ventilation, and air conditioning (HVAC) systems. These changes, which were promulgated under the American Innovation and Manufacturing (AIM) Act, are designed to phase down the use of hydrofluorocarbons (HFCs), a class of potent greenhouse gases. The AIM Act: A Game-Changer for HVAC Industry The recent changes to refrigerant regulations by the EPA signify a substantial shift in environmental policy that will have profound implications for the construction industry. For the construction industry, this means a transition to next-generation technologies that do not rely on HFCs. The AIM Act’s sector-based restrictions will affect a wide range of equipment, including refrigeration and air conditioning systems integral to building design and function. Starting January 1, 2025, the manufacturing or importing of any product in specified sectors that uses a regulated substance with a global warming potential of 700 or greater is prohibited (40 C.F.R. § 84.54(a)). The specified sectors listed include R-410A, the most common refrigerant used in the HVAC industry. The installation of systems using a regulated substance with a global warming potential of 700 or greater in specified sectors is allowed until January 1, 2026, provided that all system components are manufactured or imported before January 1, 2025. See 40 C.F.R. § 84.54 (c). “Installation” of an HVAC system is defined as the completion of assembling the system’s circuit, including charging it with a full charge, such that the system can function and is ready for its intended purpose. See 40 C.F.R. § 84.52. Reprinted courtesy of Stefanie A. Salomon, Peckar & Abramson, P.C. and Nadia Ennaji, Peckar & Abramson, P.C. Ms. Salomon may be contacted at ssalomon@pecklaw.com Ms. Ennaji may be contacted at nennaji@pecklaw.com Read the full story...

Boston Team Secures Summary Judgment Dismissal on Client’s Behalf in Serious Personal Injury Case

October 21, 2024 — Lewis Brisbois Newsroom
Boston, Mass. (October 14, 2024) - Boston Managing Partner Kenneth B. Walton and Partner Matthew M. O' Leary recently secured summary judgment on behalf of a civil engineering firm in a serious personal injury matter arising from a trip-and-fall incident in a mall parking lot. The client was retained to provide site civil engineering design for the parking lot of a local mall. The design included multiple bioretention areas known as rain gardens. In November of 2019, a woman tripped and fell while attempting to cross a rain garden to reach her car. She suffered significant bodily injuries, including a fracture of the cervical spine that resulted in partial paralysis. The woman and her husband sued the mall's owner for negligence and loss of consortium in June 2021. The owner, in turn, impleaded Lewis Brisbois' client and the lot's builder, asserting third-party claims for contribution, contractual and common law indemnity, and breach of contract. In addition, the builder cross-claimed against Lewis Brisbois' client for contribution and common law indemnity. Read the full story...
Reprinted courtesy of Lewis Brisbois

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Behavioral Science Meets Construction: Insights from Whistle Rewards

September 09, 2024 — Aarni Heiskanen - AEC Business
In this episode of the AEC Business Podcast, Aarni Heiskanen hosts Drew Carter, CEO of Whistle Rewards, and Dr. Laurel Newman, a behavioral scientist, to discuss instant rewards for driving behavioral change in construction. Laurel shares her psychology background and academic career, studying how the environment influences behavior. Drew introduces himself as a data scientist, focusing on predictive modeling. Tune in to learn how they collaborate to create motivating environments in the construction industry. Whistle Rewards is a platform specializing in rewards, recognition, and incentives in the AEC industry. It is designed to enhance employee engagement, safety compliance, performance, and technology adoption in construction companies. The Guests Drew Carter, CEO and Co-Founder at Whistle Systems, Inc. Drew is improving employee retention using data science and behavioral science. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

It’s Not What You Were Thinking!

December 10, 2024 — Daniel Lund III - Lexology
At least it is not what the lower court was thinking… but the same result for a general contractor seeking to have its comprehensive general liability insurer pay the GC’s defense related to claims for physical damage on a construction project. In reviewing the Massachusetts federal district court’s ruling in favor of the insurer, the United States First Circuit Court of Appeals posited: “The principal question is whether a general contractor’s CGL insurance policy covers damage to a non-defective part of the contractor’s project resulting from a subcontractor’s defective work on a different part of that project.” The district court had held under Massachusetts law that the insurer had no duty to defend because the lawsuit “did not allege ‘property damage’ caused by an ‘ occurrence,’ as required for coverage” under the policy (a defense that was urged by the insurer). The Court of Appeals affirmed, “albeit for different reasons.” Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Kahana Feld LLP Senior Attorney Rachael Marvin and Partner Dominic Donato Obtain Complete Dismissal of Plaintiff’s Labor Law Claims on Summary Judgment

August 19, 2024 — Rachel Marvin - Kahana Feld
Kahana Feld attorneys Rachael Marvin and Dominic Donato secured summary judgment dismissal of plaintiff’s Labor Law §§ 240(1), 241(6), and 200 claims asserted against their client, a general contractor of a housing project in Orange County, New York. The case involved a construction accident in which plaintiff fell while traversing a ramp, which was placed across an eight-foot-deep excavation trench. Plaintiff was employed by a subcontractor and was part of a crew performing the framing work on the project. The accident occurred when he exited his work area by walking across a ramp that was placed across the excavated trench, when the ramp gave way and plaintiff fell into the excavation. Read the full story...
Reprinted courtesy of Rachel Marvin, Kahana Feld
Ms. Marvin may be contacted at rmarvin@kahanafeld.com

EPA Looks to Reduce Embodied Carbon in Materials With $160M in Grants

August 19, 2024 — James Leggate - Engineering News-Record
The U.S. Environmental Protection Agency estimates that construction materials used for buildings and built infrastructure account for more than 15% of global greenhouse gas emissions. The agency now hopes to boost adoption of materials with lower embodied emissions by offering $160 million in grants to better track and ultimately reduce climate pollution associated with those materials. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story...

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES