Anaheim California Building Consultant Directory

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Climate Disasters Are an Affordable Housing Problem

October 01, 2024 — Juan Pablo Garnham & Arjuna Heim - Bloomberg
When Maui was devastated by wildfires in August 2023, some residents were initially fortunate. The neighborhood of Makawao, for example, was spared the worst effects of the fire that engulfed Lahaina, 35 miles to the west. Recently, though, we met a woman in that neighborhood who faces a different kind of threat: Her landlord has now demanded that she pay double her rent or face eviction. As housing advocates in the region, we’ve heard stories like this repeatedly, as residents report an acute fear of displacement and homelessness. A year after the fires killed more than 100 people, displaced 12,000 and disrupted the economy of the island, the disaster lingers for many in Maui and Hawai'i. Rents across the island have increased sharply, offering a cautionary tale for the rest of the US about how climate change, a housing crisis and the lack of adequate public policies can multiply the suffering of a community already in pain. Read the full story...
Reprinted courtesy of Bloomberg

Edison Utility Accused of Igniting LA Fire in Lawsuits

January 21, 2025 — Jef Feeley, Mark Chediak & Malathi Nayak - Bloomberg
Edison International Inc.’s southern California utility faces lawsuits blaming the energy provider’s equipment for igniting one of the wildfires still raging in the second-largest US metropolis. The first of several suits filed Monday was brought on behalf of a group of homeowners, renters, business owners and others with properties destroyed by the deadly Eaton Fire in the Pasadena area. The complaints allege that Southern California Edison power lines were the cause of the blaze that leveled the community of Altadena. The initial suits are expected to be followed by thousands more legal claims. Reprinted courtesy of Jef Feeley, Bloomberg, Mark Chediak, Bloomberg and Malathi Nayak, Bloomberg Read the full story...

Payne & Fears Recognized by Best Lawyers in 2025 Best Law Firms®

December 03, 2024 — Payne & Fears LLP
Payne & Fears LLP has been named to the 2025 Best Lawyers “Best Law Firms” list. This recognition highlights firms that demonstrate professional excellence, receiving outstanding ratings from both clients and peers. Payne & Fears has been ranked in the following practice areas: Metropolitan Tier 1

Orange County

Commercial Litigation
Employment Law – Management
Insurance Law
Labor Law – Management
Litigation – Labor and Employment
Litigation – Real Estate

Metropolitan Tier 2

Las Vegas

Commercial Litigation

Metropolitan Tier 3

Orange County

Litigation – Intellectual Property

Read the full story...
Reprinted courtesy of Payne & Fears LLP

Hawaii Supreme Court Reaffirms an "Accident" Includes Reckless Conduct, Finds Green House Gases are Pollutants

November 18, 2024 — Tred R. Eyerly - Insurance Law Hawaii
Answering certified questions from the federal district court, the Hawaii Supreme Court reaffirmed its prior holding that reckless conduct is an "occurrence' or accident. The court further held that green house gas (GHG) emissions were pollutants under liability policies. Aloha Petroleum, Ltd. v. National Union Fire Ins. Co. of Pittsburg, PA., et al., 2024 Haw. LEXIS 179 (Haw. Oct. 7, 2024). [Disclosure - our office was co-counsel on an amicus brief in this case filed on behalf of the United Policyholders]. The City and County of Honolulu and the County of Maui sued several fossil fuel companies, including Aloha Petroleum, Ltd., for climate change-related harms. The suits alleged that the fossil fuel industry knew beginning in the 1960s that its products would cause catastrophic climate change. Rather than mitigate their emissions, defendants concealed their knowledge of climate change, promoted climate science denial, and increased their production of fossil fuels. Defendants' actions, the complaints alleged, increased carbon emissions, which caused significant damage to the counties. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Traub Lieberman Partners Lisa Rolle, Erin O’Dea, and Nicole Verzillo Win Motion for Summary Judgment in Favor of Property Owner

September 30, 2024 — Lisa M. Rolle, Erin O’Dea, Nicole Verzillo - Traub Lieberman
Traub Lieberman Partners Lisa Rolle, Erin O’Dea, and Nicole Verzillo won motion for summary judgment in a premises liability matter brought before the Supreme Court of the State of New York, Westchester County. The Plaintiff allegedly tripped and fell in a pothole on the common driveway of five abutting properties and sustained an injury. The firm represented one of the multiple property owners. Traub Lieberman moved for summary judgment, asserting that the claims against the firm’s client should be dismissed as they did not own, operate, control or make special use of the driveway where the incident occurred. The firm also asserted that the alleged condition of the driveway that allegedly caused Plaintiff’s accident was a non-actionable, trivial defect. The firm also moved to dismiss the cross-claims asserted against them, contending that there was no evidence of negligence on behalf of the firm’s client. As such, the court found that the defect was a non-actionable, trivial defect. The firm secured dismissal of Plaintiff’s claims against the firm’s clients and against all moving and non-moving Defendants. Reprinted courtesy of Lisa M. Rolle, Traub Lieberman, Erin O’Dea, Traub Lieberman and Nicole Verzillo, Traub Lieberman Ms. Rolle may be contacted at lrolle@tlsslaw.com Ms. O'Dea may be contacted at eodea@tlsslaw.com Ms. Verzillo may be contacted at nverzillo@tlsslaw.com Read the full story...

Choice of Law Provisions in Construction Contracts

October 07, 2024 — Victoria Davies - ConsensusDocs
If you have used a ConsensusDocs® construction agreement or another industry association construction agreement for one of your projects, you are accustomed to seeing the laws of the state where the construction project is located as the governing law. There are good reasons for the laws of the state where the project is located to govern the construction agreement for the project. Even if not headquartered in the state, the parties have a presence there by virtue of their participation in the project in the state. Personnel and records that may be needed to resolve a claim may be located in the state. If there are experts that need to be engaged, they will likely need to visit the site. These reasons of efficiency and convenience, alone, may justify the parties’ decision to select the project state’s laws to govern their construction contract. However, there is also the policy interest of the project state, whose laws may even mandate that the project state’s laws govern construction contracts for in-state projects and that the parties resolve their disputes in state as well. Several states have laws that require construction disputes for projects in the state to be resolved under its laws and/or litigated or arbitrated in the state. Some states require only that its laws govern and do not also require that the dispute resolution take place in the state, but some require both – that its laws govern and the disputes be resolved there. There may be different triggers as to when the statute applies. For example, in some states, the statute applies to any construction contract for a project in the state. In others, the law may only be triggered if one of the parties is domiciled in the state. Read the full story...
Reprinted courtesy of Victoria Davies, Jones Walker LLP
Ms. Davies may be contacted at vdavies@joneswalker.com

Los Angeles Recovery Crews Begin to Mobilize as Wildfires Continue to Burn

January 21, 2025 — Scott Blair, Aileen Cho, & C.J. Schexnayder - Engineering News-Record
More than a week since wildfires broke out in the Los Angeles area stoked by hurricane-force Santa Ana winds, officials are hoping that a change in the weather will soon allow the long process of recovery to begin. Reprinted courtesy of Scott Blair, ENR, Aileen Cho, ENR and C.J. Schexnayder, ENR Mr. Blair may be contacted at blairs@enr.com Ms. Cho may be contacted at choa@enr.com Mr. Schexnayder may be contacted at schexnayderc@enr.com Read the full story...

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES