Anaheim California Building Consultant Directory

Rejection’s a Bear- Particularly in Construction

December 23, 2024 — Christopher G. Hill - Construction Law Musings
As I read through this week’s cases published in Virginia Lawyers Weekly, I came across a case posing an interesting question. The question is, “If your bid is rejected along with everyone else’s, can you complain?” The short answer set out by the Rockingham County, Virginia Circuit Court is “No.” In the case of General Excavation v. City of Harrisonburg the Court looked at the Virginia Public Procurement Act’s bid protest provisions in Va. Code 2.2-4360 and 2.2-4364(C) in the context of General Excavation’s protest of the City’s failure to award it (or anyone else for that matter) the contract on which it was the low bidder. The controlling section of the statute allows a challenge to the award or proposed award of a contract. In defending the action, the City of Harrisonburg argued that, because the Procurement Act waived some of the city’s sovereign immunity, it must be read strictly. The city further argued (somewhat ironically) that, because no award of the contract was given or even proposed, General Excavation could not bring suit because it would not be challenging the “proposed award or award” of a contract. Not surprisingly, the Rockingham County court held with the City and strictly construed the statute against General Excavation in finding that General Excavation did not have the standing necessary to bring suit under the statute. Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

Rainwater Collecting on Rooftop is not Subject to Policy's Flood Sublimits

October 15, 2024 — Tred R. Eyerly - Insurance Law Hawaii
Responding to a certified question from the First Circuit, the Supreme Judicial Court of Massachusetts determined that rainwater collecting on the insureds' rooftop and causing interior damage was not "flood" as defined in the policy and subject to sublimits. Zurich Am. Ins. Co. v. Medical Properties Trust, Inc., 2024 Mass. LEXIS ___ (Mass. July 23, 2024). A severe thunderstorm caused heavy rain and strong winds which damaged a hospital. The hospital was owned by Medical Properties Trust, Inc. (MPT) and leased to Steward Health Care System LLC (Steward). Ground water accumulated and flooded the basement. Rainwater also accumulated on the hospital's parapet roofs and on the second-story courtyard, and eventually seeped through the parapet roofs and courtyard to the hospital's upper floors, causing damage to the building and property within. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

‘The Ground Just Gave Out’: How a Storm’s Fury Ravaged Asheville

October 07, 2024 — Michael Smith, Devon Pendleton, Claire Ballentine & Michael Sasso - Bloomberg
Eric Becker was at his vacation home in western North Carolina, in a community bordering the Pisgah National Forest and Blue Ridge Parkway, when the rain began to pour. Becker, co-founder of the private wealth management firm Cresset, lives in Florida for most of the year. He had lived through a hurricane — but nothing like what he saw during Helene. “Mud was liquefying around tree bases. You could see the root systems,” said Becker, who first began visiting the Asheville area 20 years ago and was smitten by its natural scenery, excellent food and lively arts and music scene. “The ground just gave out.” Becker is part of a wave of affluent homebuyers who have flocked to the southern Appalachian region. Transplants from wealth managers and retirees to artists and young outdoors enthusiasts have helped create a real estate goldrush in cities including Asheville, where home prices have climbed 69% in the past five years. Reprinted courtesy of Michael Smith, Bloomberg, Devon Pendleton, Bloomberg, Claire Ballentine, Bloomberg and Michael Sasso, Bloomberg Read the full story...

Seattle Developer Defaults on Renovated Office Buildings

December 23, 2024 — Anna Edgerton - Bloomberg
A major developer in downtown Seattle defaulted on a loan backed by two of its most prized office properties, including one that formerly housed a branch of the Federal Reserve Bank of San Francisco. Firms tied to Martin Selig Real Estate are in default on a more than $200 million loan, according to letters from lender Acore Capital dated Nov. 15 that were filed in Washington’s King County. The buildings would change ownership 30 days after that notice if no other action is taken, according to the letters. Read the full story...
Reprinted courtesy of Anna Edgerton, Bloomberg

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

More Musings on Why I Mediate

November 18, 2024 — Christopher G. Hill - Construction Law Musings
Whew! I’m back. And yes, I know it’s been a while (it has been a busy year, both personally and professionally). Hopefully, this will be the first of at least a few more consistent posts here at Construction Law Musings. Now, on with the post: Over the last few weeks, I’ve had a surge in mediation, both in my capacity as a mediator and as counsel for construction industry clients. These recent events have reaffirmed what I have always believed to be true, namely that no construction case is impossible to settle and avoid the cost and expense of litigation. I was also reminded of why I became a certified mediator and of the satisfaction that I get from helping individuals and construction companies find a business solution and closure. Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Scott Saylin Expands Employment Litigation and Insurance Litigation Team at Payne & Fears

September 23, 2024 — Payne & Fears LLP
Scott Saylin has joined Payne & Fears LLP as a Law Clerk in the firm’s Employment Litigation Group and Insurance Litigation Group. Before his time at Payne & Fears, Scott served as a law clerk for Cascadia Healthcare in Boise, Idaho. “We are pleased to welcome Scott Saylin back to the firm. He was with us as a summer associate before completing his final year of law school at George Washington University,” said Amy Patton, the group’s co-chair. “Scott has fantastic potential to develop into an excellent litigator and will be an asset to our team.” Get to Know Scott What activities do you enjoy outside of work? Pickle ball, long walks, beach trips, cooking, watching the Lakers games, and playing the guitar & piano. Read the full story...
Reprinted courtesy of Payne & Fears LLP

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES