Anaheim California Building Consultant Directory

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

ENR 2024 Water Report: Managers Look to Potable Water Reuse

July 15, 2024 — Pam McFarland - Engineering News-Record
With nearly all seven states within the 250,000-sq-mile Colorado River basin scrambling to conserve their apportionments from the river system’s increasingly depleted resources, interest in securing alternative local drinking water supplies is soaring. Reprinted courtesy of Pam McFarland, Engineering News-Record Ms. McFarland may be contacted at mcfarlandp@enr.com Read the full story...

Immigrants' Legal Status Eyed Over Roles in New York Fake Injury Lawsuits

January 07, 2025 — Richard Korman - Engineering News-Record
Edison Fernando Pesantez Ramon says that early on the morning of Sept. 29, 2021, while working on a building renovation project on 96th Street in Manhattan, he tripped and fell badly on a staircase. Read the full story...
Reprinted courtesy of Richard Korman, ENR
Mr. Korman may be contacted at kormanr@enr.com

Damage Caused Not by Superstorm Sandy, But by Faulty Workmanship, Not Covered

December 10, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court adopted the Report and Recommendations (R&R) of the magistrate judge, finding there was no coverage for faulty workmanship in replacing a roof for an apartment complex. Burlington Ins. Co. v. PCGNY Corp., 2024 U.S. Dist. LEXIS 167814 (S.D. N. Y. Sept. 16, 2024). Skyline Restoration was hired by the apartment complex to replace the apartments' roofs. Skyline subcontracted with PCGNY Corporation. The roofs were later damaged during Superstorm Sandy. Defendant Affiliated FM Insurance Company ("Affilliated"), a subrogee of the owner of the apartment complex, sued Skyline for defective, faulty and unworkmanlike removal and replacement of the roofs. Skyline filed a Third-Party Complaint against PCGNY. Plaintiff Burlington Insurance Company filed this coverage action against Skyline, Affiliated, PCGNY and others seeking a declaration that it had no duty to defend and/or indemnify PCGNY and/or Skyline, and that it was permitted to withdraw from the defense of PCGNY. Burlington filed a motion for summary judgment. The motion was referred to the magistrate judge who recommended that Burlington be granted a declaration that it had no duty to defend or indemnify PCGNY or Skyline and that it be allowed to withdraw from the defense of PCGNY in the underlying case. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

New York's New Gateway: The Overhaul of John F. Kennedy International Airport

September 09, 2024 — Aileen Cho - Engineering News-Record
On the cusp of the 70th anniversary of the originally named New York Airport’s opening in Queens, N.Y., a blue-ribbon panel in 2017 released a report to the governor of New York: The facility, once popularly known as Idlewild Airport, needed a comprehensive master plan and a total transformation. In the seven years since, builders at John F. Kennedy International Airport have been anything but idle, and the speed at which that $19-billion transformation of the roads and terminals is occurring could be called wild. Reprinted courtesy of Aileen Cho, Engineering News-Record Ms. Cho may be contacted at choa@enr.com Read the full story...

Construction Litigation Roundup: “Give a Little Extra …”

July 31, 2024 — Daniel Lund III - Lexology
Surplus lines insurers in Louisiana are considered by the state to be “an alternative type of property and casualty insurance coverage for consumers who cannot get coverage on the standard market … for specialty risk or high-risk situations….” As a quid pro quo for undertaking the exceptional risk, a surplus lines insurer argued to the United States Fifth Circuit Court of Appeals that an arbitration clause within its surplus line policy should be enforceable, notwithstanding a Louisiana statute applying to the insurance industry and prohibiting terms in insurance policies “delivered or issued for delivery” in Louisiana which have the effect of “[d]epriving the courts of this state of the jurisdiction or venue of action against the insurer.” La. R.S. 22:868. Historically in Louisiana, arbitration clauses have been understood to divest courts of jurisdiction, and, consequently, §22:868 has been held to memorialize an “anti-arbitration policy,” although the statute does not specifically mention arbitration. Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Thirteen Payne & Fears Attorneys Honored by Best Lawyers

August 19, 2024 — Payne & Fears LLP
Congratulations to the 13 Payne & Fears attorneys included in the 2025 Edition of “Lawyer of the Year,” The Best Lawyers In America®, and Best Lawyers: Ones to Watch®. Attorneys have been recognized in the following practice areas: 2025 Edition “Lawyer of the Year” Orange County Benjamin A. Nix

Trade Secrets Law

Daniel F. Fears

Litigation – Labor and Employment

Read the full story...
Reprinted courtesy of Payne & Fears LLP

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES