Anaheim California Building Consultant Directory

Finding Insurer's Declaratory Relief Action Raises Unsettled Questions of State Law, Case is Dismissed

November 05, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court for the District of Hawaii dismissed the insurer's action for declaratory relief because it raised issues that were unsettled by Hawaii courts. Association of Apartment Owners of Lahaina Residential Condominium, et al., No. 1-24-cv-00075-JAO-BMK, Order Granting AOAO's Motion to Dismiss (D. Haw. Aug. 29, 2024). The case addressed whether a property damage exclusion barred coverage over an owner's claim that a condominium association and its property manager failed to obtain adequate insurance before the condominium's property was damaged by the Maui wildfire in August 2023. Great American filed suit seeking a declaration that it had no duty to defend or indemnify the Association and the property manage, Quam Properties Hawaiiana, Inc., in connection with a demand for mediation submitted to the Association and Quam on behalf of one of the owners. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Fall 2024 Legislative Update:

October 28, 2024 — Joshua Lane - Ahlers Cressman & Sleight PLLC
Review of (a) RCW 60.30.010-020, (b) RCW 49.17.530, (c) RCW 19.95.020, (d) RCW 39.116.005, et seq., (e) RCW 36.70B.080, and (f) RCW 39.12.010 and .13 While much of the focus on the recent legislative updates has been on RCW 39.04.360, a number of other legislative changes may also have significant impacts on Washington’s construction industry. Six of these changes are summarized below. A. RCW 60.30.010 and .020 (SSB 6108) – Concerning Retainage on Private Construction, Effective June 6, 2024 Last year, ESSB 5528 imposed restrictions and obligations related to retainage and timing of final payment on private (non-public works) projects. It capped retainage at 5%, required prompt payment on final payments, and required owners to accept a retainage bond on private construction projects, excluding single-family residential construction less than 12 units. This year, SSB 6108 adds suppliers to the statutes (RCW 60.30.010 and 0.020) pertaining to retainage on private construction projects. Read the full story...
Reprinted courtesy of Joshua Lane, Ahlers Cressman & Sleight PLLC
Mr. Lane may be contacted at joshua.lane@acslawyers.com

Thirteen Payne & Fears Attorneys Honored by Best Lawyers

August 19, 2024 — Payne & Fears LLP
Congratulations to the 13 Payne & Fears attorneys included in the 2025 Edition of “Lawyer of the Year,” The Best Lawyers In America®, and Best Lawyers: Ones to Watch®. Attorneys have been recognized in the following practice areas: 2025 Edition “Lawyer of the Year” Orange County Benjamin A. Nix

Trade Secrets Law

Daniel F. Fears

Litigation – Labor and Employment

Read the full story...
Reprinted courtesy of Payne & Fears LLP

Five Issues to Consider in Government Contracting (Or Any Contracting!)

September 02, 2024 — David Adelstein - Florida Construction Legal Updates
The appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting. Issue #1- Patently Ambiguous Specifications The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Challenging a Termination for Default

September 23, 2024 — David Adelstein - Florida Construction Legal Updates
No contractor wants to be terminated for default. It is the harshest contractual recourse. It is a recourse that has implications, particularly in the public sector. However, a party needs to be in a position to support the basis of the termination for default, and the terminated party, in most instances, should not be in a position to imply accept the basis of the default. This applies regardless of the project. In the federal context: “When a contractor challenges a default termination, the government bears the burden of establishing the validity of the termination.” Sergent’s Mechanical Systems, Inc. v. U.S., 2024 WL 4048175, *7 (Fed.Cl. 2024) (internal quotation and citation omitted). Once the government establishes the default, “the contractor bears the burden of establishing that the default was excused by fault of the government.” Id. at *8 (internal quotation and citation omitted). Relevant considerations as to whether the contractor is in default include the contractor’s failure to meet contract specifications or the required schedule. Sergent’s Mechanical Systems, supra, at *8. “[T]here is ‘a requirement that the contractor give reasonable assurances of performance in response to a validly issued cure notice.” Id. (internal quotation and citation omitted). Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Wildfire Risk Scores and Insurance Placement: What You Should Know

July 15, 2024 — Louis "Dutch" Schotemeyer & Molly L. Okamura - Newmeyer Dillion
What Are Wildfire Risk Scores and How Are They Calculated? Wildfire risk scores are scores assigned to properties by third-party vendors based on the likelihood of direct or indirect exposure to a wildfire. Wildfire risk scores can be a factor used by insurance companies when making coverage decisions. Additionally, wildfire risk scores can be a helpful metric for real estate developers to consider when determining whether to buy a piece of property. There are a variety of vendors that use unique methods to calculate wildfire risk scores. For example, CoreLogic, FireLine, and RedZone are vendors used by insurance companies in California. Some vendors' scoring scales are from 1-10, and some are from 1-100, but generally the higher the score, the higher the likelihood of a wildfire impacting the property. There is no national, standardized scoring scale. Reprinted courtesy of Louis "Dutch" Schotemeyer, Newmeyer Dillion and Molly L. Okamura, Newmeyer Dillion Mr. Schotemeyer may be contacted at dutch.schotemeyer@ndlf.com Ms. Okamura may be contacted at molly.okamura@ndlf.com Read the full story...

AAA Revises Construction Industry Arbitration Rules and Mediation Procedures

July 22, 2024 — Patrick McKnight - The Dispute Resolver
The American Arbitration Association (AAA) recently revised its Construction Industry Arbitration Rules and Mediation Procedures (“the Rules”). Several notable changes went into effect March 1, 2024, involving the scope of confidentiality, regular and fast track procedures, and updates to certain monetary thresholds. I. Revisions to Regular Track Procedures Rule 45: Confidentiality For the first time, confidentiality is now the default standard. Under Rule 45(a), arbitrators must keep all matters confidential unless otherwise required by law, court order or the agreement of the parties. Rule 45(b) allows a mediator to issue confidentiality orders and “take measures for protecting trade secrets and confidential information.” Rule 7: Consolidation and Joinder Under the new provisions, consolidation and joinder requests must be filed before confirmation of the Merits Arbitrator’s appointment. This language eliminates a previous option that allowed confirmation up to 90 days after filing of such requests. A failure to timely respond to a joinder request will result in a waiver of objections. Now, a party must establish both good cause and prejudice for a successful joinder request after confirmation of the arbitrator. Read the full story...
Reprinted courtesy of Patrick McKnight, Fox Rothschild LLP
Mr. McKnight may be contacted at pmcknight@foxrothschild.com

America’s Bridges and the Need for Bridge Infrastructure Investment

January 07, 2025 — Lisa D. Love - The Dispute Resolver
During the October 2024 meeting of the American Bar Association’s Forum on Construction held in Pittsburgh, a city of many bridges, the importance of bridges to our nation’s transportation infrastructure was apparent. Just two years ago, the Forbes Avenue bridge in Pittsburgh collapsed—resulting in several vehicles and a bus falling into a ravine. Ten people were injured in the event. It was later reported that the bridge had received a “poor” rating but was still permitted to remain open to traffic. The event resulted in several lawsuits which, just this past September, the City of Pittsburgh requested $500,000 from the city council to settle. The Forbes Avenue bridge is hardly a unique case and is just one example of the litigation that can ensue if we fail to maintain our aging infrastructure. The State of Our Nation’s Bridges As of June 2024, the United States has more than 616,000 bridges located on public roads, including interstate highways, U.S. highways, state and county roads, as well as publicly accessible bridges on federal and tribal lands. Read the full story...
Reprinted courtesy of Lisa D. Love, JAMS

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES