ANAHEIM CALIFORNIA BUILDING CONSULTANT
DIRECTORY AND CAPABILITIES

Understanding Entitlement to Delays and Proper Support

December 10, 2024 — Andrew G. Vicknair - The Dispute Resolver
In a previous post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method. Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay. If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

New York Construction Practice Team Obtains Summary Judgment and Dismissal of Labor Law Claims

October 01, 2024 — Lewis Brisbois Newsroom
New York, N.Y. (August 23, 2024) – In Trujillo-Cruz v. City of New York, et al., New York Partner Inderjit Dhami, a member of New York Partner Meghan A. Cavalieri’s Construction Practice Team, recently obtained summary judgment and dismissal of the plaintiff's Labor Law §240(1), §241(6) and §200 claims dismissing the entire case against national developer and construction company clients. The plaintiff alleged to have sustained injuries as the result of a construction site accident occurring on July 11, 2018, while in the scope of his employment as a laborer in connection with the construction/renovation of a residential apartment building in Brooklyn, New York. Specifically, the plaintiff alleged that he was injured when he was coming down from a ladder and fell on a 2”x 4”, causing him disabling injuries. The plaintiffs’ counsel articulated a $3 million settlement demand. Labor Law §240(1) imposes absolute liability on a defendant where an injured worker engaged in the performance of covered construction work establishes that a safety device proved inadequate to shield him from elevation-related harm, and that the defendant’s failure to provide an adequate safety device proximately caused the injuries alleged. The plaintiff first testified that he stepped on the 2” x 4” after he came down off of the ladder, but his counsel then prompted him to recalibrate his testimony by asking whether the accident arose when he was coming down the ladder or after he had come down off of the ladder. The plaintiff changed his testimony, alleging that the accident arose as he was coming down the ladder and that he remained partially on the ladder when he stepped on the piece of formwork and fell. Inderjit argued that the plaintiff’s reframing of his deposition testimony was immaterial for purposes of the Labor Law § 240 (1) analysis. Irrespective of whether the plaintiff was on solid ground or had one foot on the ladder at the time of the occurrence, his Labor Law § 240 (1) claim was unavailing in that the accident did not arise as a result of the type of extraordinary elevation-related peril protected by Labor Law § 240 (1). Justice Maslow agreed and dismissed the plaintiff’s Labor Law § 240 (1) claims. Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Real Estate & Construction News Roundup (7/17/24) – Housing Inflation to Remain High, Proptech Investment to Fall and Office Vacancy Rates to Reach Peak in 2025

August 26, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, construction backlog to see positives signs, regional banks to be conservative on buybacks, U.S. metro areas to permit few new housing units, and more!

• Venture capital investments in proptech and adjacent companies fell 14.3% in the first half of the year. (Leslie Shaver, Multifamily Dive)
• The expectation of interest rate cuts by the Federal Reserve later this year due to easing inflation and cooling economic growth is a positive sign for construction backlog. (Sebastian Obando, Construction Dive)
• The U.S. office real estate sector is now in three markets, each with different performance, but the overall office vacancy rate will reach a 21.6% peak in the second half of 2025. (Nish Amarnath, Construction Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Fee Simple!

November 11, 2024 — Daniel Lund III - Lexology
Following the grant of summary judgment by a Nebraska federal court on a construction claim, the prevailing subcontractor sought recovery of attorney’s fees, but received pushback from its opponent based upon the Federal Rules of Civil Procedure. The general contractor urged “that attorney’s fees are ‘special damages’ that must be specifically pleaded within a complaint under Federal Rule of Civil Procedure 9(g).” The GC said that a prayer for “a judgment for… costs, interest, and attorney’s fees be entered” – without further asserting a statutory or factual basis for the recovery – is insufficient. The subcontractor shot back that “it complied with the requirements of Rule 9(g) because its prayer for relief expressly referenced attorney’s fees, and the request for such fees was based on the facts asserted in the pleadings themselves.” Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

---

Busting Major Alternative-Lending Myths

July 22, 2024 — Warren Miller - Construction Executive
Alternative capital is a broad term for financing provided by institutions or firms that typically fall outside of the purview of the larger, regulated institutions (i.e., not traditional banks). While these funding sources may not always be the first option for many businesses, alternative lending is a perfect option for many small and mid-sized capital-intensive companies, like construction companies, which often require fast access to capital that is incompatible with the stringent and laborious processes imposed by traditional banks. Construction companies should take a closer look at alternative financing, understand its benefits, and evaluate its usefulness for achieving their unique funding requirements. REALITY 1: ALTERNATIVE LENDING IS SAFE AND PROVEN Private lending has been around for a long time, and has become increasingly common since the 1990s, when major consolidation took place in the banking industry. As the large, consolidated banks set their sights on providing loans to large enterprises, they left a gap in the small and mid-size market that was filled by alternative lenders. By 2000, alternative lenders had overtaken traditional banks for the majority of corporate loans. Stricter regulation of banks following the Global Financial Crisis of 2007 intensified underwriting standards for bank loans and further diminished banks’ appetites for SMB lending. Reprinted courtesy of Warren Miller, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Real Estate & Construction News Roundup (10/1/24) – Hybrid Work Technologies, AI in Construction and the Market for Office Buildings

November 05, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, commercial mortgage bond market in trouble, commercial real estate investments, pressure on mortgage REITs, and more!

• Short-term issues facing U.S. commercial real estate have made it an investment opportunity and values have bottomed out. (CNBC)
• As organizations report plans to shake up their real estate portfolios, the flight to quality spurs interest in space planning, amenities and hybrid work technologies. (Joe Burns, Facilities Dive)
• The conversation about AI’s potential benefits and risks has been a common refrain in construction recently. (Matthew Thibault, Construction Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Real Estate & Construction News Roundup (9/4/24) – DOJ Sues RealPage, Housing Sales Increase and U.S. Can’t Build Homes Fast Enough

October 07, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, environmental regulations tighten for commercial properties, Wells Fargo sells most of its commercial mortgage services business, first-time home buyers struggle with housing affordability, and more!

• The U.S. Department of Justice announced that it is suing the real estate company RealPage, saying it engaged in a price-fixing scheme to drive up rents. (Jennifer Ludden, NPR)
• As environmental regulations for commercial buildings and properties tighten across the U.S., green leases and technologies offer owners and operators opportunities to reduce their portfolios’ carbon footprints, generate cost savings and further align with ESG goals. (Nish Amarnath, Construction Dive)
• Wells Fargo & Co. agreed to sell most of its commercial mortgage servicing business to Trimont LLC, ceding the title of biggest US commercial and multifamily mortgage servicer to the Atlanta-based firm. (Hannah Levitt and Scott Carpenter, Yahoo)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Nine ACS Lawyers Recognized by Best Lawyers®

September 02, 2024 — Ahlers Cressman & Sleight PLLC
Departing from our blog’s typical coverage of construction related issues, Ahlers Cressman & Sleight PLLC is proud to announce that nine members of our firm have been recognized by Best Lawyers® in 2025 in America. Recognition by Best Lawyers® is based entirely on peer review and is designed to reflect the consensus opinion of leading lawyers about the professional abilities of their colleagues. Lawyers can be nominated by clients and other lawyers. After nomination, ballots are generated and distributed to lawyers. Voters are asked how likely they would be to refer a case to the nominee and to give a rating and additional comments. Ballots are designed based on the voter’s practice area and geographic region. After feedback is analyzed, Best Lawyers® research staff ensures nominees are in good standing with the ethics committee of their state bar and selects lawyers for recognition. Read the full story...
Reprinted courtesy of Ahlers Cressman & Sleight PLLC

---