Anaheim California Building Consultant Directory

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

OSHA Finalizes PPE Fitting Requirement for Construction Workers

December 31, 2024 — Jonathan H. Schaefer - Construction Law Zone
On December 11, 2024, the Occupational Safety and Health Administration (OSHA) announced it finalized a revision to the personal protective equipment (PPE) standard for the construction industry. The final rule adds specific language to the existing standard requiring employers to provide properly fitting PPE for construction industry workers. This change aligns the construction industry with the standards in place for the general industry. According to OSHA, many types of PPE must properly fit workers. Improperly sized PPE can ineffectively protect workers, creating new hazards for them, such as oversized gloves or protective clothing being caught in machinery and discouraging use because of discomfort or poor fit. OSHA stated that the longstanding issue with improperly fitting PPE particularly impacted women, as well as physically smaller or larger workers. Read the full story...
Reprinted courtesy of Jonathan H. Schaefer, Robinson+Cole
Mr. Schaefer may be contacted at jschaefer@rc.com

Bally's Secures Funding for $1.7B Chicago Casino and Hotel Project

August 12, 2024 — Annemarie Mannion - Engineering News-Record
Plans for a $1.7-billion casino and adjacent 34-story hotel are advancing in Chicago as the gaming operator reports it has secured $940 million to complete funding for the project and has set demolition for a printing press building now occupying the site for this summer. Reprinted courtesy of Annemarie Mannion, Engineering News-Record Ms. Mannion may be contacted at manniona@enr.com Read the full story...

When Cyber Crooks Steal Payments, Think Insurance Makes Up The Loss? Think Again.

November 18, 2024 — Richard Korman - Engineering News-Record
In Summer 2023, the payment system for a small office and warehouse project that Beck Properties was developing for itself in South St. Paul, Minn., seemed to be running smoothly. Emails were criss-crossing back and forth and paper checks were landing in mailboxes. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story...

Wildfire Risk Harms California Home Values, San Francisco Fed Study Finds

August 26, 2024 — Laura Curtis - Bloomberg
California’s wildfires are weighing on home prices more than in the past, and insurance availability does little to help in areas considered to be at higher risk, according to a Federal Reserve Bank of San Francisco study. “Our results suggest that property values have been more adversely impacted in recent years by being close to past wildfires than was the case previously,” economists Leila Bengali, Fernanda Nechio and Stephanie Stewart wrote in a paper published Monday on the Fed bank’s website. While the effect of the proximity may be relatively small now, the economists warned “this pattern may become stronger in years to come if residential construction continues to expand into areas with higher fire risk and if trends in wildfire severity continue,” the study cautioned. Read the full story...
Reprinted courtesy of Laura Curtis, Bloomberg

Hawaii Supreme Court Finds Climate Change Lawsuit Barred by “Pollution Exclusion”

November 05, 2024 — Jason Taylor - Traub Lieberman Insurance Law Blog
On October 7, 2024, the Hawaii Supreme Court answered the question of whether an “accident” includes an insured’s reckless conduct in emitting harmful greenhouse gases (“GHGs”) and whether such emissions are “pollutants” as defined in a general liability policy’s pollution exclusion. In Aloha Petro., Ltd. v. National Union Fire Insurance Co. of Pitt., PA, No., 2024 Haw. LEXIS 179 (Oct. 7, 2024), the Hawaii Supreme Court answered in the affirmative as to both certified questions from the United States District Court for the District of Hawaii, holding that an insured’s reckless conduct can be an “accident” and that GHGs are “pollutants” under the policies’ pollution exclusions. In the underlying case, the County of Honolulu and the County of Maui (the “Counties”) sued Aloha Petroleum, Ltd. (“Aloha”) and several other fossil fuel companies for climate change-related harms. Namely, the Counties alleged that the fossil fuel industry knew that its products would cause catastrophic climate change, and rather than mitigating their emissions, defendants concealed such knowledge, promoted climate science denial, and increased their production of fossil fuels. Aloha was allegedly on notice that its products caused harmful climate change through its former parent company, Phillips 66, and its current parent company, Sunoco. Given this knowledge, the District Court determined that the Counties allegations constituted reckless conduct by Aloha. Read the full story...
Reprinted courtesy of Jason Taylor, Traub Lieberman
Mr. Taylor may be contacted at jtaylor@tlsslaw.com

Ensuing Loss Provision Salvages Coverage for Water Damage Claim

September 16, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The Court of Appeals for the D.C. Circuit reversed the district court's finding of no coverage and found that the ensuing loss provision provided coverage for water damage. 3524 East Cap Venture, LLC, et al. v. Weschester Fire Ins. Co., et al., 104 F. 4th 193 (D.C. Cir. 2024). Plaintiff 3534 East Cap Venture, LLC, a real-estate developer, hired plaintiff McCullough Construction, LLC, to build a residential and retail complex. Defendants Westchester Fire Insurance Company and Endurance American Insurance Company issued identical builders' risk policies, which covered the building while it was under construction. Each insurer was responsible for half of any qualifying losses. The policies covered loss caused by or resulting from water damage. The policies, however, excluded loss caused by "dampness of atmosphere" or by "[e]xtremes or changes in temperature." But the exclusions contained an exception if "loss by an insured peril ensues." Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Construction Defect Claim Survives Insurer's Summary Judgment Motion Due to Lack of Evidence

December 23, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The court denied the insurer's motion for summary judgment on a construction defect claim due to lack of evidence. Statesboro Erectors, Inc. v. Owners Ins. Co., 2024 U.S. Dist. LEXIS 176555 (N.D. Ga. Sept. 30, 2024). Griffco was the general contractor for a construction project. King Steel was hired as the "steel fabricator." King Steel subcontracted with Statesboro Erectors to complete certain construction work at the site. Statesboro agreed to the complete, proper and safe erection of the structural steel. A steel collapse occurred at the construction site. According to King Steel, the collapse "appeared to have occurred due to lack of temporary cables or bracing for steel columns." Because of the collapse, King Steel was required to supply additional materials to replace the structural damage caused by the collapse. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES