Anaheim California Building Consultant Directory

Not a Waiver for All: Maryland Declines to Apply Subrogation Waiver to Subcontractors

September 23, 2024 — Gus Sara - The Subrogation Strategist
In Lithko Contr., LLC v. XL Ins. Am. Inc., No. 31, Sept. Term, 2023, 2024 Md. LEXIS 256, the Supreme Court of Maryland considered whether a tenant who contracted for the construction of a large warehouse facility waived its insurer’s rights to subrogation against subcontractors when it agreed to waive subrogation against the general contractor. The court ultimately decided that the unambiguous language of the subrogation waiver in the development agreement between the parties did not extend to subcontractors. The court also held that the tenant’s requirement that subcontracts include a subrogation waiver did not, in this case, impose a project-wide waiver on all parties. The court, however, found that the requirement that the subcontracts include a similar, but not identical, waiver provision rendered the subcontract’s waiver clauses ambiguous and remanded the case to the lower court to determine if the parties to the development agreement – i.e., Duke Baltimore LLC (“Duke”) and Amazon.com.dedc, LLC (“Amazon”) – intended that the waiver clause in the subcontracts covered claims against subcontractors. This case involved roof and structural damage to a warehouse in Baltimore, Maryland that Duke owned. In March 2014, Amazon entered into a development agreement with Duke for the construction of the warehouse. Amazon also agreed to subsequently lease the warehouse from Duke. Although Amazon essentially owned and/or developed the project, the development agreement identified Duke as “Landlord” and Amazon as “Tenant.” Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

Athens, Ohio, Sues to Recover Nearly $722,000 After Cyber Attack

January 21, 2025 — Jeff Yoders - Engineering News-Record
In November, Athens, Ohio, officials sent nearly $722,000 to a bank account they believed was set up by its contractor, Pepper Construction, to receive payment for its work on a fire station headquarters. The request was actually a sophisticated cyber attack that took advantage of a construction payment system that often does not allow clients processing invoices to directly know those behind the email addresses making the requests. Read the full story...
Reprinted courtesy of Jeff Yoders, ENR
Mr. Yoders may be contacted at yodersj@enr.com

Deterioration of Bridge Infrastructure Is Increasing Insurance Needs

December 03, 2024 — Grace Calengor - Construction Executive
As the world is taken by storm—literally, with increasing hurricanes, tornadoes, wildfires and more—insuring construction projects and infrastructure is becoming more complicated yet more necessary. Sean Pender, senior vice president of construction and development at CAC Specialty, is a leading specialty insurance broker and advisor. As major-storm season for the Northern hemisphere rounds out, he speaks with Construction Executive about the potential risk and insurance implications to the process of ensuring proper repairs, replacements and other forms of maintenance to one of the country’s most pivotal pieces of infrastructure: bridges. What does insurance coverage look like for building bridges in various environments throughout the country? Insurance is essential to protect the entity that owns the bridge during construction. Bridges under construction are at the highest risk of collapse because they are not yet fully stabilized and are exposed to severe weather and natural disasters, which could cause significant damage to the structure or injury to workers and civilians. Therefore, comprehensive liability insurance programs—typically with coverage limits of $50 to $100 million or higher—are crucial, especially with activities on or over waterways. Reprinted courtesy of Grace Calengor, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Five Issues to Consider in Government Contracting (Or Any Contracting!)

September 02, 2024 — David Adelstein - Florida Construction Legal Updates
The appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting. Issue #1- Patently Ambiguous Specifications The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Kahana Feld Named to the Orange County Register 2024 Top Workplaces List

January 14, 2025 — Linda Carter - Kahana Feld
ORANGE COUNTY – Dec. 31, 2024 – Kahana Feld is pleased to announce that the firm has been named a 2024 Top Workplace by the Orange County Register. This is the second year in a row that Kahana Feld has been named to the Orange County Top Workplaces list. The Top Workplaces list is based solely on employee feedback gathered through a third-party survey. The confidential survey uniquely measures the employee experience and its component themes, including employees feeling Respected & Supported, Enabled to Grow, and Empowered to Execute. “Inclusion on this list is a testament to Kahana Feld’s dedication to employee satisfaction,” said Firmwide Managing Partner Amir Kahana. “Having a positive and supportive culture has always been a top priority for us, and it will continue to be a driving force in our growth and success.” Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

ASCE Statement on House Passage of the Water Resources Development Act of 2024

August 05, 2024 — Marsia Geldert-Murphey, P.E., President of the American Society of Civil Engineers
WASHINGTON — The American Society of Civil Engineers (ASCE) commends the House of Representatives for passing H.R. 8812, the bipartisan Water Resources Development Act (WRDA) for 2024. The House WRDA 2024 bill will help improve America's ports and inland waterways, enhance flood risk management and storm risk reduction programs, and prioritize ecosystem restoration. While we urge the Senate to swiftly vote on its version of WRDA, we are encouraged that our nation's critical water resources infrastructure remains a congressional priority. The House version of WRDA includes several key provisions to enhance the safety of America's dams and levees, which each received a 'D' on the 2021 Report Card for America's Infrastructure, as well as provisions to modernize the nation's inland waterways system, which received a 'D+' in the 2021 Report Card. This includes one of ASCE's top legislative priorities for this year, the reauthorization of the National Dam Safety Program through 2028. But beyond the reauthorization, this bill reduces restrictions on the amount of funds states can receive in National Dam Safety Program State Assistance Grants; improves access to the High Hazard Potential Dam Rehabilitation Grant Program; and requires the incorporation of low-head dams into the National Inventory of Dams. Each of these provisions are critical to ensuring the long-term safety of our nation's dams and ASCE applauds the House for their inclusion. Furthermore, ASCE was pleased to see that the House legislation extends the National Levee Safety Program through 2033, which will help support the establishment of state levee safety programs, develop and publish national guidelines for levee safety, and enhance flood protection nationwide. While these measures are not included in the Senate version of WRDA, we encourage lawmakers to ensure they are included in a final conference version of the bill. We thank the House of Representatives for moving forward WRDA 2024 and strongly encourage the Senate to pass its version so that Congress can keep this vital water resources legislation on a biennial schedule and ensure our nation's dams, levees, ports, and inland waterways can support the American economy and protect public safety. ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS Founded in 1852, the American Society of Civil Engineers represents more than 160,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel.

More (and Simpler) Options Under New Oregon Retention Law

October 21, 2024 — Michael Yelle - Ahlers Cressman & Sleight PLLC
Similar to the changes made by the Washington Legislature last year, the Oregon Legislature recently changed its retention law. Oregon public works agencies and large commercial project owners are now required to accept surety bonds in lieu of withholding retainage on construction projects. There is also no longer a requirement to deposit retention funds in an interest-bearing escrow account. The owner or public agency must accept the bond in lieu of retainage unless specific grounds exist. For example, public agencies must find there is “good cause” for rejection of the bond based on the “unique project circumstances. Private owners have less discretion to reject a bond and if the bond meets the statutory requirements, per ORS 701.435(1)(a) “the owner and lender shall accept” the bond “in lieu of all or any portion of the retainage…” Courts have not analyzed when “good cause” exists for public agencies to reject bonds or exactly what will allow a private owner to reject a bond. However, an agency or owner cannot have a general policy to reject retention bonds. The statute does not provide next steps if the contractor disagrees with a decision to reject the bond. It may be necessary to proceed under the contract’s dispute resolution procedure or it may be more appropriate to take the issue directly to the courts. Read the full story...
Reprinted courtesy of Michael Yelle, Ahlers Cressman & Sleight PLLC
Mr. Yelle may be contacted at michael.yelle@acslawyers.com

Understanding Entitlement to Delays and Proper Support

December 10, 2024 — Andrew G. Vicknair - The Dispute Resolver
In a previous post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method. Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay. If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES