Anaheim California Building Consultant Directory

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

Alleged Negligent Misrepresentation on Condition of Home is Not an Occurrence Causing Property Damage

December 17, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The court found that even if the insured's negligent misrepresentations constituted an accident, the disclosures did not cause physical damage to the property. Wood v. USAA Cas. Ins. Co., 2024 U.S. Dist. LEXIS 180624 (D. S.C. Sept. 12, 2024). The insured, Clinton Wood, purchased a townhome in January 2014. After the purchase, Wood experienced leaks and significant water intrusion, as did other townhome owners in the same development. Wood and the other owners retained an engineer to evaluate the cause of the water damage. The engineer determined that the water intrusion was caused by defects in the design and construction of the residence. The engineer told Wood that the proposed repairs would not adequately address and resolve the water intrusion and leaks, and that the problems would continue even if repairs were made. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Los Angeles Is Burning. But California’s Insurance Industry Is Not About to Collapse.

January 14, 2025 — Jerry Theodorou - R Street
Five fires are raging in the Los Angeles outskirts currently – the Palisades Fire, the Eaton Fire, the Lidia Fire, the Sunset Fire, and the Hurst Fire. They have been stoked by a trifecta of 100 mph wind gusts, elevated heat, and bone-dry grass and shrubs serving as tinder. The severity of the fires has raised questions about the role of climate change in the conflagrations and insurers’ claims-paying capacity. But while we recognize the immensity of the hardship and tragedy to many Angelenos from the fires, we also must recognize that California’s insurance industry is not about to collapse. Many have ignored or missed recent reforms to California insurance regulation that are poised to make the private market more sustainable, and help stem an exodus of insurers from the Golden State. Whether the intensity of wildfires is exacerbated by climate change is an open question. An R Street study found that natural catastrophes have increased in severity, but not in frequency. And the main reason catastrophe severity has risen is an increase in the built environment – there is simply more stuff now to be destroyed. Read the full story...
Reprinted courtesy of Jerry Theodorou, R Street
Mr. Theodorou may be contacted at jtheodorou@rstreet.org

Real Estate & Construction News Roundup (10/16/24) – Chevron Ruling’s Impact on Construction Industry, New Kind of Public Housing and Policy Recommendations from Sustainable Building Groups

November 11, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, Hurricane Helene affects infrastructure, California Gov. Gavin Newsom signs bills aimed at renter protections, Federal Reserve kick-off rate-easing cycle, and more!

Hurricane Helene illustrates how communities and infrastructure across the U.S. are unprepared for the extreme weather driven by climate change. (Julie Strupp, Construction Dive)
The Supreme Court’s June Chevron ruling will likely have a seismic impact on laws that pertain to the construction industry. (Julie Strupp, Construction Dive)
California Gov. Gavin Newsom signed three bills changing renter protection practices in the state last month including new requirements for security deposit deductions and restrictions on certain fees. (Mary Salmonsen, Multifamily Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Federal Court Sets High Bar for Pleading Products Liability Cases in New Jersey

November 11, 2024 — Lian Skaf - The Subrogation Strategist
Products liability is an area of law that both sides of the aisle vigorously litigate. Like in most litigation, products liability claims provide subrogation attorneys with an important means of prosecuting cases against manufacturers, sellers, and other entities in the stream of commerce. Of course, these claims also come with numerous “buyer beware” requirements. New Jersey allows products liability claims and the United States District Court for the District of New Jersey (District Court) clarified how such claims should be plead in Cambridge Mut. Fire Ins. Co. a/s/o David Krug vs. Stihl, Inc., No. 22-05893, 2024 U.S. Dist. LEXIS 178804 (D. N.J.). After becoming subrogated to the rights of its insured, Cambridge Mutual Fire Insurance Company (Cambridge) filed suit against Stihl, Inc. (Stihl) in the Superior Court of New Jersey, Morris County, Law Division. Stihl then removed the case to federal court. Once in federal court, Stihl filed a motion to dismiss the action. The District Court granted the motion, doing so in part with prejudice and in part without prejudice. Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

AI in Construction: What Does It Mean for Our Contractors?

December 17, 2024 — Patrick Scarpati - Construction Executive
Artificial intelligence is revolutionizing the construction industry by enhancing efficiency, safety and decision-making throughout the project lifecycle. AI in construction involves the application of advanced technologies like machine learning, computer vision and data analytics to various construction processes. Through AI, machines can learn and imitate human cognitive functions. The possibilities may sound endless, but as an industry traditionally looking from the outside in at technology, we must first step back to educate ourselves on the basics. This paper is meant to function as a starting point in your journey to understand AI and its potential impact on the construction industry. By reading through definitions, construction use cases and considerations, the reader should walk away with a base level of knowledge to ensure they can actively participate in future conversations on AI in construction. Reprinted courtesy of Patrick Scarpati, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Fall 2024 Legislative Update:

October 28, 2024 — Joshua Lane - Ahlers Cressman & Sleight PLLC
Review of (a) RCW 60.30.010-020, (b) RCW 49.17.530, (c) RCW 19.95.020, (d) RCW 39.116.005, et seq., (e) RCW 36.70B.080, and (f) RCW 39.12.010 and .13 While much of the focus on the recent legislative updates has been on RCW 39.04.360, a number of other legislative changes may also have significant impacts on Washington’s construction industry. Six of these changes are summarized below. A. RCW 60.30.010 and .020 (SSB 6108) – Concerning Retainage on Private Construction, Effective June 6, 2024 Last year, ESSB 5528 imposed restrictions and obligations related to retainage and timing of final payment on private (non-public works) projects. It capped retainage at 5%, required prompt payment on final payments, and required owners to accept a retainage bond on private construction projects, excluding single-family residential construction less than 12 units. This year, SSB 6108 adds suppliers to the statutes (RCW 60.30.010 and 0.020) pertaining to retainage on private construction projects. Read the full story...
Reprinted courtesy of Joshua Lane, Ahlers Cressman & Sleight PLLC
Mr. Lane may be contacted at joshua.lane@acslawyers.com

The 2023 Term of the Supreme Court: Administrative and Regulatory Law Rulings

December 03, 2024 — Anthony B. Cavender - Gravel2Gavel Construction & Real Estate Law Blog
It is instructive to review the Supreme Court’s record in its most recent term, concentrating on regulatory and administrative law cases, which are usually back-burner issues. But not this term. The Supreme Court began the current term on October 7, 2024. The Court has already chosen many cases to review in the new term, and it promises to be as interesting as the 2023 term, which produced several significant rulings affecting regulatory and administrative law, chiefly the Loper Bright Enterprises ruling. Loper Bright overturned the Court’s landmark administrative law ruling of Chevron, USA v. Natural Resources Defense Council, Inc., 467 U.S. 837 (1984). The Background to Loper Bright In 1984, the Supreme Court decided Chevron USA, Inc. v. National Resource Defense Council. (See 467 U.S. 839 (1984).) The unanimous decision, written by Justice Stevens, reversed then-D.C. Circuit Judge Ruth Bader Ginsburg’s ruling that set aside EPA’s Clean Air Act “bubble policy,” which was intended to provide regulatory relief from certain EPA permitting requirements. Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES