Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision
September 02, 2024 —
Bill Wilson - Construction Law ZoneIn NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:
NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.
Read the full story...Reprinted courtesy of
Bill Wilson, Robinson & Cole LLPMr. Wilson may be contacted at
wwilson@rc.com
Business Risk Exclusion Dooms Coverage for Construction Defect Claim
January 21, 2025 —
Tred R. Eyerly - Insurance Law HawaiiThe First Circuit, following Massachusetts law, found that coverage for allegations against the insured contractor for faulty workmanship were barred by the policy's (j) (6) Exclusion. Admiral Ins. Co. v. Tocci Bldg. Corp., 2024 U.S. App. LEXIS 28439 (1st Cir. Nov. 8, 2024).
Tocci Building Corporation was the construction manager for an apartment project owned by Toll JM EB Residential Urban Renewal LLC (Toll). There were several work quality issues and delays on the project and Toll eventually terminated Tocci for alleged mismanagement of the project. Toll then filed a lawsuit against Tocci.
The claims against Tocci included (1) damage to sheetrock resulting from faulty roof work; (2) mold formation resulting from inadequate sheathing and water getting into the building; and (3) damage to a concrete slab, wood framing, and underground pipes resulting from soil and settlement due to improperly backfill and soil compaction.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
New Research Shows Engineering Firms' Impact on Economy, Continued Optimism on Business Climate
October 28, 2024 —
The ACEC Research InstituteWASHINGTON – The ACEC Research Institute – the leading source of original research for the business of engineering – released the results of two important studies on the current and future state of the engineering industry, and its role in the overall U.S. economy.
The reports, the
2024 Economic Assessment of the Engineering & Design Services Industry and the
Engineering Business Sentiment Report for 2024 Q4, both point to continued optimism for the industry and its firms, though somewhat softened compared to previous quarters.
"This research shows the outsized impact the engineering industry has on the American economy," said ACEC Research Institute Chair Mike Carragher. "As the engineering industry's contributions grow year over year, the Institute's research helps firm executives position their businesses for a successful future."
All told, the industry added $656 billion to the U.S. GDP in 2023, supported well over five million jobs directly or indirectly, and contributed $92 billion to federal tax coffers, with an additional $44 billion in state and local taxes.
Overall, the report found that the engineering and design services industry has continued to build on its year-over-year post-COVID gains, growing 5.5% in 2023 to $436 billion, with much of that growth driven by infrastructure projects. Non-residential and non-building construction, flush with government funding through the IIJA and Inflation Reduction Act, remained on an upward trajectory.
New York Appellate Team Obtains Affirmance of Dismissal of Would-Be Labor Law Action Against Municipal Entities
August 12, 2024 —
Lewis Brisbois NewsroomNew York, N.Y. (July 11, 2024) - In Charlot v. City of New York, ___ A.D.3d ___, 2024 NY Slip Op 03161 (2d Dep’t 2024), New York Associate Dean Pillarella, a member of the Appellate Practice, recently obtained an affirmance of the lower court’s dismissal of the plaintiff’s action against the City of New York (“the City”) for failure to timely serve a notice of claim. New York Partner Meghan Cavalieri, a member of the Construction Practice, and her team authored and argued the initial motion to dismiss.
The plaintiff alleged to have sustained injuries as a result of a construction-site accident on December 8, 2020, on City-owned property in the course of the construction of a school by the New York City School Construction Authority. N.Y. General Municipal Law (“GML”) § 50-e(1)(a), requires service of a notice of claim within 90 days after the claim arises as a condition precedent to the commencement of a tort action. The plaintiff served no notice of claim until June 2021 and commenced an action in January 2022, alleging violations of N.Y. Labor Law §§ 240(1), 241(6), and 200. Given the plaintiff’s failure to comply with GML § 50-e(1)(a), Meghan and her team rejected the notices of claim as untimely. The plaintiff then moved for leave to deem the notices of claim timely served nunc pro tunc. In response, Meghan and her team opposed the motion and cross-moved to dismiss the action.
Read the full story...Reprinted courtesy of
Lewis Brisbois
When Every Drop Matters, Cities Turn to Watertech
November 25, 2024 —
James B. Bobotek - Gravel2Gavel Construction & Real Estate Law BlogWe all need water to survive—but access to the liquid lifeline isn’t always a given. With a shifting climate and ever-increasing agricultural and industrial demands on this limited commodity, UNICEF predicts that by 2025, half of the world’s population could be living in areas facing water scarcity. On top of the obvious resource drains, many countries are losing surprising amounts of potable water to leaks. For example, in the United States alone, an estimated 6 billion gallons of treated drinking water seep out of its supply every day due to aging pipelines and undetected leaks.
“Smart” water innovations may offer conservation solutions, though. As part of an overall smart city scheme, where internet of things (IoT) devices work hand-in-hand with AI to improve daily life, many municipalities are giving their water systems a makeover. From new meters to irrigation and pipeline maintenance, we look at some of the key intelligent technologies that endeavor to improve how we harness our water supply.
Read the full story...Reprinted courtesy of
James B. Bobotek, PillsburyMr. Bobotek may be contacted at
james.bobotek@pillsburylaw.com
In Phoenix, Crews Thread Needle With $730M Broadway Curve Revamp
July 31, 2024 —
Scott Blair - Engineering News-RecordMotorists scrambling to dart across three lanes of traffic when merging onto the freeway. Vehicles slowing to a crawl due to extremely curved exit ramps. Commuters enduring agonizing backups as three freeways converge in a tight footprint. Bicyclists and pedestrians sweating through long detours to traverse freeways.
Reprinted courtesy of
Scott Blair, Engineering News-Record
Mr. Blair may be contacted at blairs@enr.com
Read the full story...
Newport Beach Partners Jeremy Johnson, Courtney Serrato, and Associate Joseph Real Prevailed on a Demurrer in a Highly Publicized Shooting Case!
November 11, 2024 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPBremer Whyte Brown & O’Meara’s Partners Jeremy Johnson, Courtney Serrato, and Associate Joseph Real prevailed on a Demurrer in a highly publicized shooting case.
Plaintiffs filed a lawsuit alleging negligence, negligent hiring, supervision and retention, and public nuisance against BWB&O’s clients, a highly recognized hospitality and lifestyle company with nightlife and restaurant venues, in addition to other celebrity defendants. Plaintiffs were the victims of a shooting that occurred by an unknown individual(s) outside and near the restaurant/venue owned by BWB&O’s clients.
Plaintiffs alleged it was BWB&O’s clients that were responsible for the third parties’ criminal acts because BWB&O’s clients attracted more people than the venue’s capacity, causing people to occupy the street, sidewalk, and property nearby. Plaintiffs further alleged that BWB&O’s client should have anticipated or known that criminal conduct, including gun violence, would take place.
Read the full story...Reprinted courtesy of
Dolores Montoya, Bremer Whyte Brown & O'Meara LLP
Top 10 Insurance Cases of 2024
January 21, 2025 —
Jeffrey J. Vita & Michelle A. Grieco - Saxe Doernberger & Vita, P.C.Federal and state courts tackled a myriad of interesting insurance-related issues this past year. The U.S. Supreme Court also surprisingly addressed coverage issues in 2024, in not one—but two—decisions. It is rare for the Supreme Court to confront insurance coverage issues which usually involve matters of state law. The highest court’s assessment of the nuances of insurance to resolve maritime choice of law issues and interpret an insurer’s role in bankruptcy proceedings is indicative of the significant role that insurance coverage plays in resolving commercial disputes.
Additionally, 2024 included a pivotal opinion from the 5th Circuit, which welcomed the principle that negligent construction can constitute “property damage” under a CGL policy if it causes a harmful change to the property. Elsewhere in the country, the Hawaii Supreme Court ruled that reckless conduct can qualify as an “accident” under a CGL policy’s definition of “occurrence”; however, the court simultaneously ruled that greenhouse gases fall within the scope of “pollutants” under the policy’s pollution exclusion. Cyber coverage decisions were also prominent, and the 5th Circuit chimed in with an interesting decision interpreting the scope of coverage afforded under a “system failure” provision. These decisions represent a mere sampling of the multitude of insurance issues courts nationwide have grappled with in 2024.
Reprinted courtesy of
Jeffrey J. Vita, Saxe Doernberger & Vita, P.C. and
Michelle A. Grieco, Saxe Doernberger & Vita, P.C.
Mr. Vita may be contacted at JVita@sdvlaw.com
Ms. Grieco may be contacted at MGrieco@sdvlaw.com
Read the full story...Express Warranty Trumping Spearin’s Implied WarrantyEmbattled SNC-Lavalin Files Ethics Appeal, Realigns StructureWall Failure Due to Construction Defect Says InsurerCA Supreme Court: Right to Repair Act (SB 800) is the Exclusive Remedy for Residential Construction Defect Claims – So Now What?Tort Claims Against an Alter Ego May Be Considered an Action “On a Contract” for the Purposes of an Attorneys’ Fees Award under California Civil Code section 1717Nine Firm Members Recognized as Super Lawyers and Rising StarsFamed NYC Bridge’s Armor Is Focus of Suit Against French CompanyConstruction Employment Rises in Half of the StatesDeveloper’s Failure to Plead Amount of Damages in Cross-Complaint Fatal to Direct Action Against Subcontractor’s Insurers Based on Default JudgmentDocumenting Contract Changes in ConstructionIt Pays to Review the ‘Review the Contract Documents’ Clause Before You Sign the ContractSB800 Is Now Optional to the Homeowner?Public-Employee Union Fees, Water Wars Are Key in High Court RulingsToronto Contractor Bondfield Wins Court Protection as Project Woes MountMultifamily Building Pushes New Jersey to Best Year since 2007Local Government’s Claims on Developer Bonds Dismissed for Failure to Pursue Administrative RemediesGarlock Five Years Later: Recent Decisions Illustrate Ongoing Obstacles to Asbestos Trust TransparencyBreak out the Neon: ‘80s Era Davis-Bacon “Prevailing Wage” Definition Restored in DOL Final RuleUnlocking the Hidden Power of Zoning, for Good or Bad7 Sustainability Ideas for Modular Classrooms in the Education Industry (guest post)Pennsylvania Supreme Court Will Not Address Trigger for DEP Environmental Cleanup Action at This TimeNo Prejudicial Error in Refusing to Give Jury Instruction on Predominant CauseFirm Seeks to Squash Subpoena in Coverage CD CaseFifth Circuit Requires Causal Distinction for Ensuing Loss Exception to Faulty Work ExclusionHOA Group Speaking Out Against Draft of Colorado’s Construction Defects BillInsurer Fails to Establish Prejudice Due to Late NoticeQuick Note: Not In Contract With The Owner? Serve A Notice To Owner.Floating Crane on Job in NYC's East River Has a Storied Past of Cold War IntrigueTenants Underwater: Indiana Court of Appeals Upholds Privity Requirement for Property Damage Claims Against ContractorsMixed Reality for Construction: Applicability and RealityFirst Railroad Bridge Between Russia and China Set to OpenOSHA/VOSH RoundupNLRB Hits Unions with One-Two Punch the Week Before Labor DayASCE Statement on House Passage of the Water Resources Development Act of 2024Future Army Corps Rulings on Streams and Wetlands: Changes and Delays AheadPatent or Latent: An Important Question in Construction DefectsHunton Insurance Head Interviewed Concerning the Benefits and Hidden Dangers of Cyber InsuranceTexas Considers a Quartet of Construction BillsAlexis Crump Receives 2020 Lawyer Monthly Women in Law AwardDamp Weather Not Good for WoodBehavioral Science Meets Construction: Insights from Whistle RewardsLoose Bolts Led to Sagging Roof in Construction Defect ClaimQuick Note: Unenforceable Language in Arbitration ProvisionUniversity of Tennessee’s New Humanities Building Construction Set to BeginA Construction Stitch in TimeShow Me the Money: The Good Faith Dispute Exception to Prompt Payment PenaltiesHousing Sales Hurt as Fewer Immigrants Chase Owner DreamTrump Soho May Abandon Condos to Operate Mainly as HotelBHA has a Nice Swing: Firm Supports Wounded Warrior Project at WCC SeminarASCE Statement on House Passage of Infrastructure Investment and Jobs Act 
