Anaheim California Building Consultant Directory

Finding Insurer's Declaratory Relief Action Raises Unsettled Questions of State Law, Case is Dismissed

November 05, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court for the District of Hawaii dismissed the insurer's action for declaratory relief because it raised issues that were unsettled by Hawaii courts. Association of Apartment Owners of Lahaina Residential Condominium, et al., No. 1-24-cv-00075-JAO-BMK, Order Granting AOAO's Motion to Dismiss (D. Haw. Aug. 29, 2024). The case addressed whether a property damage exclusion barred coverage over an owner's claim that a condominium association and its property manager failed to obtain adequate insurance before the condominium's property was damaged by the Maui wildfire in August 2023. Great American filed suit seeking a declaration that it had no duty to defend or indemnify the Association and the property manage, Quam Properties Hawaiiana, Inc., in connection with a demand for mediation submitted to the Association and Quam on behalf of one of the owners. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.comASCE Statement on Devastating Impacts of Hurricane HeleneOctober 07, 2024 — Marsia Geldert-Murphey, P.E., President - American Society of Civil Engineers
WASHINGTON, DC. – We are deeply saddened by the tragic loss of life across six states, in addition to the immeasurable damages caused by Hurricane Helene throughout the Southeast this past week. Hundreds of communities are without power. Citizens cannot move safely from one place to another. And in its wake, the storm has left many without drinking water and sewage services. As civil engineers, our first priority when we design and build the structures that connect us is the public's safety and well-being; we are heartbroken to see so many lives lost or upended by Hurricane Helene. As someone who has experienced losing everything in a catastrophic flood event, I have seen first-hand the need for making communities more resilient, and the consequences of failing to do so. Although hurricanes have consistently been a threat in the U.S., particularly in the Southeast, extreme weather events and 500-year floods are increasing in regularity and our aging infrastructure systems were not built to withstand storms of this magnitude. Total prevention of loss of life or property damage can never be guaranteed, but Helene is a reminder of the importance of widespread adoption of up-to-date, modern building codes and standards. We are thankful for the hard work of first responders, the military, and other organizations working around the clock to save lives and meet the immediate needs of people affected by this storm. As communities begin the

Thirteen Payne & Fears Attorneys Honored by Best Lawyers

August 19, 2024 — Payne & Fears LLP
Congratulations to the 13 Payne & Fears attorneys included in the 2025 Edition of “Lawyer of the Year,” The Best Lawyers In America®, and Best Lawyers: Ones to Watch®. Attorneys have been recognized in the following practice areas: 2025 Edition “Lawyer of the Year” Orange County Benjamin A. Nix

Trade Secrets Law

Daniel F. Fears

Litigation – Labor and Employment

Read the full story...
Reprinted courtesy of Payne & Fears LLP

Five Issues to Consider in Government Contracting (Or Any Contracting!)

September 02, 2024 — David Adelstein - Florida Construction Legal Updates
The appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting. Issue #1- Patently Ambiguous Specifications The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Challenging a Termination for Default

September 23, 2024 — David Adelstein - Florida Construction Legal Updates
No contractor wants to be terminated for default. It is the harshest contractual recourse. It is a recourse that has implications, particularly in the public sector. However, a party needs to be in a position to support the basis of the termination for default, and the terminated party, in most instances, should not be in a position to imply accept the basis of the default. This applies regardless of the project. In the federal context: “When a contractor challenges a default termination, the government bears the burden of establishing the validity of the termination.” Sergent’s Mechanical Systems, Inc. v. U.S., 2024 WL 4048175, *7 (Fed.Cl. 2024) (internal quotation and citation omitted). Once the government establishes the default, “the contractor bears the burden of establishing that the default was excused by fault of the government.” Id. at *8 (internal quotation and citation omitted). Relevant considerations as to whether the contractor is in default include the contractor’s failure to meet contract specifications or the required schedule. Sergent’s Mechanical Systems, supra, at *8. “[T]here is ‘a requirement that the contractor give reasonable assurances of performance in response to a validly issued cure notice.” Id. (internal quotation and citation omitted). Another Reminder that Your Construction Contract is Only as Good as Those Signing ItDecember 17, 2024 — Christopher G. Hill - Construction Law Musings
Here at Construction Law Musings, we beat the constant drum that “Wildfire Risk Scores and Insurance Placement: What You Should KnowJuly 15, 2024 — Louis "Dutch" Schotemeyer & Molly L. Okamura - Newmeyer Dillion
What Are Wildfire Risk Scores and How Are They Calculated? Wildfire risk scores are scores assigned to properties by third-party vendors based on the likelihood of direct or indirect exposure to a wildfire. Wildfire risk scores can be a factor used by insurance companies when making coverage decisions. Additionally, wildfire risk scores can be a helpful metric for real estate developers to consider when determining whether to buy a piece of property. There are a variety of vendors that use unique methods to calculate wildfire risk scores. For example, CoreLogic, FireLine, and RedZone are vendors used by insurance companies in California. Some vendors' scoring scales are from 1-10, and some are from 1-100, but generally the higher the score, the higher the likelihood of a wildfire impacting the property. There is no national, standardized scoring scale. Reprinted courtesy of Louis "Dutch" Schotemeyer, Newmeyer Dillion and Molly L. Okamura, Newmeyer Dillion Mr. Schotemeyer may be contacted at dutch.schotemeyer@ndlf.com Ms. Okamura may be contacted at molly.okamura@ndlf.com Read the full story...

AAA Revises Construction Industry Arbitration Rules and Mediation Procedures

July 22, 2024 — Patrick McKnight - The Dispute Resolver
The American Arbitration Association (AAA) recently revised its Construction Industry Arbitration Rules and Mediation Procedures (“the Rules”). Several notable changes went into effect March 1, 2024, involving the scope of confidentiality, regular and fast track procedures, and updates to certain monetary thresholds. I. Revisions to Regular Track Procedures Rule 45: Confidentiality For the first time, confidentiality is now the default standard. Under Rule 45(a), arbitrators must keep all matters confidential unless otherwise required by law, court order or the agreement of the parties. Rule 45(b) allows a mediator to issue confidentiality orders and “take measures for protecting trade secrets and confidential information.” Rule 7: Consolidation and Joinder Under the new provisions, consolidation and joinder requests must be filed before confirmation of the Merits Arbitrator’s appointment. This language eliminates a previous option that allowed confirmation up to 90 days after filing of such requests. A failure to timely respond to a joinder request will result in a waiver of objections. Now, a party must establish both good cause and prejudice for a successful joinder request after confirmation of the arbitrator. Read the full story...
Reprinted courtesy of Patrick McKnight, Fox Rothschild LLP
Mr. McKnight may be contacted at pmcknight@foxrothschild.com

America’s Bridges and the Need for Bridge Infrastructure Investment

January 07, 2025 — Lisa D. Love - The Dispute Resolver
During the October 2024 meeting of the American Bar Association’s Forum on Construction held in Pittsburgh, a city of many bridges, the importance of bridges to our nation’s transportation infrastructure was apparent. Just two years ago, the Forbes Avenue bridge in Pittsburgh collapsed—resulting in several vehicles and a bus falling into a ravine. Ten people were injured in the event. It was later reported that the bridge had received a “poor” rating but was still permitted to remain open to traffic. The event resulted in several lawsuits which, just this past September, the City of Pittsburgh requested $500,000 from the city council to settle. The Forbes Avenue bridge is hardly a unique case and is just one example of the litigation that can ensue if we fail to mainta

Ahlers Cressman & Sleight PLLC Recognized Among The Top 50 Construction Law Firms TM of 2024 by Construction Executive

July 15, 2024 — Ahlers Cressman & Sleight PLLC
ACS is proud to announce that it has once again been ranked among The Top 50 Construction Law Firms in the Construction Executive 2023 rankings. Since its first publication in 2003, Construction Executive magazine has served as the leading source for news, market developments, and business issues impacting the construction industry, and its articles are designed to help owners and top managers run a

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES