Anaheim California Building Consultant Directory

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

Anatomy of a Data Center

October 28, 2024 — Robert A. James & Matt Olhausen - Gravel2Gavel Construction & Real Estate Law Blog
Traditional and social media are thick with reports and predictions of the remarkable increase in size, power consumption and significance of data centers. Not only technology companies but real estate and energy developers, investment funds, lenders, and professionals of all stripes are in or determined to enter this sector. Our inboxes are full—it’s data center this, data center that. But what exactly is a data center? What infrastructure, technology and human resources come together to create and sustain one of these localized points of computation? By understanding their components, we can glean some understanding of the business, public policy and (our focus) legal issues that arise before and during their operation. In this article, we cite key characteristics of a reference Blackacre Data Center, with occasional glances at other (real) structures that offer variations on themes. Blackacre is a composite of several centers we have encountered in our law practice. These facilities differ widely in size, location and functions, so your mileage will vary. Reprinted courtesy of Robert A. James, Pillsbury and Matt Olhausen, Pillsbury Mr. James may be contacted at rob.james@pillsburylaw.com Mr. Olhausen may be contacted at matt.olhausen@pillsburylaw.com Read the full story...

With Historic Removal of Four Dams, Klamath River Flows Again Unhindered

October 21, 2024 — Tim Newcomb - Engineering News-Record
In a period of 16 months, four dams built between 1903 and 1962 came down as part of a monumental effort to clear 35 miles of the Klamath River spanning Oregon and California. The project owner, the Klamath River Renewal Corp., describes it as the largest dam removal effort in U.S.—and possibly world—history. Reprinted courtesy of Tim Newcomb, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story...

NLRB Finalizes Rule for Construction Industry Unions to Obtain Majority Support Representational Status

September 23, 2024 — Aaron C. Schlesinger - Peckar & Abramson, P.C.
On July 26, 2024, the National Labor Relations Board (“NLRB”) issued its Fair Choice – Employee Voice Final Rule (“Final Rule”), which takes effect September 30, 2024. The Final Rule eases the process for unions in the construction industry to convert their status as collective bargaining representative of bargaining unit employees from Section 8(f) to 9(a) of the National Labor Relations Act (“Act”) simply by placing certain recognitional acceptance language in their collective bargaining agreements. As a result, construction industry employers should review their collective bargaining agreements prior to signing to determine if such language exists. Section 9(a) Non-Construction Industry Employers In most industries, not including construction, union recognitional status as collective bargaining representative of the employer’s employees is governed by Section 9(a) of the Act. In order for a Union to obtain recognitional status under Section 9(a), the union must either: (1) file a petition with the NLRB showing support of 30% of the proposed bargaining unit via employee executed authorization cards and win an election of 51% of the employees in the proposed bargaining unit who actually vote; or (2) by reaching an agreement with the employer that the union possesses employee executed authorization cards from 51% of the proposed bargaining unit, which has been confirmed by a neutral arbitrator pursuant to a card count. Once such status is achieved, the union and employer are required to meet and bargain towards reaching a collective bargaining agreement covering the terms and conditions of employment of the union represented employees. A Section 9(a) union cannot have its recognitional status revoked absent the loss of majority support of the employees it represents. Read the full story...
Reprinted courtesy of Aaron C. Schlesinger, Peckar & Abramson, P.C.
Mr. Schlesinger may be contacted at aschlesinger@pecklaw.com

In Appellate Division First, New York Appellate Team Successfully Invokes “Party Finality” Doctrine to Obtain Dismissal of Appeal for Commercial Guarantors

December 23, 2024 — Dean Pillarella - Lewis Brisbois
New York, N.Y. (November 20, 2024) - In Roc-Le Triomphe Associates, LLC v. DeSouza, 2024 NY Slip Op 05654 (1st Dep’t 2024), Associate Dean Pillarella, a member of the Appellate Practice, successfully invoked the party finality doctrine to obtain the dismissal of an appeal for the firm’s commercial guarantor clients. The action concerned rent allegedly due and owing under a commercial lease by the lease’s tenant and guarantors. Pursuant to a 2022 order, the guarantors were awarded summary judgment and dismissal of all claims against them, with the landlord’s claims against the tenant left intact. After the decision and order was served with notice of entry by the prevailing party, the landlord did not file a notice of appeal from the order but, instead, filed a notice of appeal from a later judgment months after the time to appeal the order had expired. Read the full story...
Reprinted courtesy of Dean Pillarella, Lewis Brisbois
Mr. Pillarella may be contacted at Dean.Pillarella@lewisbrisbois.com

More Musings on Why I Mediate

November 18, 2024 — Christopher G. Hill - Construction Law Musings
Whew! I’m back. And yes, I know it’s been a while (it has been a busy year, both personally and professionally). Hopefully, this will be the first of at least a few more consistent posts here at Construction Law Musings. Now, on with the post: Over the last few weeks, I’ve had a surge in mediation, both in my capacity as a mediator and as counsel for construction industry clients. These recent events have reaffirmed what I have always believed to be true, namely that no construction case is impossible to settle and avoid the cost and expense of litigation. I was also reminded of why I became a certified mediator and of the satisfaction that I get from helping individuals and construction companies find a business solution and closure. Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

New York’s Highest Court Weighs in on N.Y. Labor Law

September 23, 2024 — Bill Wilson - Construction Law Zone
N.Y. Labor Law § 241(6) requires owners and contractors to provide reasonable and adequate protection and safety to persons employed at or lawfully frequenting a construction site. If a worker is injured on a construction site and establishes a violation of a specific and applicable Industrial Code regulation, both the owner and contractor will be held vicariously liable for the worker’s injury, without regard to their fault and even in the absence of control or supervision of the worksite. The Court of Appeals of New York recently addressed the broad scope of the Labor Law in the context of slipping hazards. In Bazdaric v. Almah Partners, LLC, 41 N.Y.3d 310 (2024), the plaintiff, an injured painter, slipped and fell on a plastic covering placed over an escalator in an area he was assigned to paint. The plaintiff claimed that the plastic covering was a foreign substance for purposes of Industrial Code 12 NYCRR 23-1.7(d) because it was not part of the escalator. Industrial Code 12 NYCRR 23-1.7(d) states:

Slipping hazards. Employers shall not suffer or permit any employee to use a floor, passageway, walkway, scaffold, platform or other elevated working surface which is in a slippery condition. Ice, snow, water, grease and any other foreign substance which may cause slippery footing shall be removed, sanded or covered to provide safe footing.

Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Construction Defect Disputes: Know Your Measure of Damages!!!!!

January 21, 2025 — David Adelstein - Florida Construction Legal Updates
Remember this: know your measure of damages in a construction defect dispute. If you don’t, as shown below, the outcome can be unforgiving. The measure of damages is one of your most important elements of proof. You are filing suit for damages; thus, knowing what you can reasonably recovery is paramount. In a recent dispute, Bandklayder Development, LLC v. Sabga, 50 Fla.L.Weekly D91e (Fla. 3d DCA 2025), a residential developer sold a single-family house while it was under construction in an as-is purchase agreement. Post-closing, the purchasers claimed defects and served a Florida Statutes Chapter 558 notice of construction defects letter. The purchaser subsequently initiated a construction defect lawsuit. During the nonjury trial, the purchaser’s expert testified that the purchasers suffered damages approximating $323,000 calculated as of January 19, 2022 (which was the date of the expert’s report). The expert further testified that the cost to finish the incomplete/defective work increased by 35% at the date of the May 2023 trial. However, the expert never testified as to the amount of damages as of the date of the contractual breach, which at the latest, would have been in April 2018 when the notice of construction defects letter was sent (or, at its earliest, June 2017 when closing occurred). At trial, the judge entered judgment for the purchasers in the amount of about $425,0000. This was reversed on appeal with judgment to be entered in favor of the developer. Why? Because the purchasers employed the wrong measure of damages and the only thing that prevented them from introducing the right measure of damages was within their control. Harsh outcome for not applying the correct measure of damages! Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES