Anaheim California Building Consultant Directory

Colorado Court of Appeals’ Ruling Highlights Dangers of Excessive Public Works Claims

August 26, 2024 — David M. McLain – Colorado Construction Litigation
In the case of Ralph L. Wadsworth Construction Company, LLC v. Regional Rail Partners (2024 COA 78), the Colorado Court of Appeals reviewed a complex contract dispute related to the design and construction of a transit rail line. The project, commissioned by the Regional Transportation District (“RTD”), involved a collaboration between Regional Rail Partners and Ralph L. Wadsworth Construction Company (“Wadsworth”) to build the North Metro Rail Line between Denver Union Station and Thornton. Key Facts:

Contracts and Payments: Regional Rail Partners contracted with Wadsworth to perform specific construction tasks with a total contract value of $60,210,783. By the time of the trial, Regional Rail had paid almost $58 million of this amount.
Disputes and Delays: The project faced numerous delays and disputes, leading to Wadsworth claiming significant financial damages attributed to these disruptions. In April 2018, Wadsworth’s expert estimated that Regional Rail owed them $12,408,496.60.

Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

Challenging a Termination for Default

September 23, 2024 — David Adelstein - Florida Construction Legal Updates
No contractor wants to be terminated for default. It is the harshest contractual recourse. It is a recourse that has implications, particularly in the public sector. However, a party needs to be in a position to support the basis of the termination for default, and the terminated party, in most instances, should not be in a position to imply accept the basis of the default. This applies regardless of the project. In the federal context: “When a contractor challenges a default termination, the government bears the burden of establishing the validity of the termination.” Sergent’s Mechanical Systems, Inc. v. U.S., 2024 WL 4048175, *7 (Fed.Cl. 2024) (internal quotation and citation omitted). Once the government establishes the default, “the contractor bears the burden of establishing that the default was excused by fault of the government.” Id. at *8 (internal quotation and citation omitted). Relevant considerations as to whether the contractor is in default include the contractor’s failure to meet contract specifications or the required schedule. Sergent’s Mechanical Systems, supra, at *8. “[T]here is ‘a requirement that the contractor give reasonable assurances of performance in response to a validly issued cure notice.” Id. (internal quotation and citation omitted). Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

When Every Drop Matters, Cities Turn to Watertech

November 25, 2024 — James B. Bobotek - Gravel2Gavel Construction & Real Estate Law Blog
We all need water to survive—but access to the liquid lifeline isn’t always a given. With a shifting climate and ever-increasing agricultural and industrial demands on this limited commodity, UNICEF predicts that by 2025, half of the world’s population could be living in areas facing water scarcity. On top of the obvious resource drains, many countries are losing surprising amounts of potable water to leaks. For example, in the United States alone, an estimated 6 billion gallons of treated drinking water seep out of its supply every day due to aging pipelines and undetected leaks. “Smart” water innovations may offer conservation solutions, though. As part of an overall smart city scheme, where internet of things (IoT) devices work hand-in-hand with AI to improve daily life, many municipalities are giving their water systems a makeover. From new meters to irrigation and pipeline maintenance, we look at some of the key intelligent technologies that endeavor to improve how we harness our water supply. Read the full story...
Reprinted courtesy of James B. Bobotek, Pillsbury
Mr. Bobotek may be contacted at james.bobotek@pillsburylaw.com

“A No-Lose Proposition?”

October 07, 2024 — Daniel Lund III - Lexology
A Miller Act payment bond surety and its principal general contractor both sued in federal court in New Orleans by a project subcontractor sought to compel arbitration the claims against both contractor and surety based on an indisputably enforceable arbitration clause in the subcontract. This was urged to avoid separate actions against the contractor (arbitration) and its surety (litigation), even though the surety was not a party to the subcontract and, therefore, not a party to the arbitration clause. In the face of the lack of an express agreement to arbitrate, the contractor and contractor argued that “no federal statute or policy prohibits all of Plaintiff’s claims from proceeding to arbitration….” Additionally, those parties urged that the surety should be allowed to affirmatively compel arbitration because the surety “would otherwise have the ability to assert the right to compel arbitration as a defense….” The New Orleans federal district court was unpersuaded:

“[D]istrict courts within this circuit have recognized that ‘Miller Act claims by a subcontractor for unpaid labor and materials are separate and distinct from those for general breach of contract… [and] arbitration and Miller Act suits, are not, per se, inconsistent with one another.’…[A]bsent express contractual intent to subject Miller Act claims to arbitration, the court [will] not force the parties to arbitrate claims against nonparties to the contract at issue…. [C]laims against a surety, which was a non-signatory to the contract, would not be subject to arbitration without any contractual basis to do so.”

Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Quick Note: Staying, Not Dismissing, Arbitrable Disputes Under Federal Arbitration Act

July 31, 2024 — David Adelstein - Florida Construction Legal Updates
As you hopefully know from posted articles, arbitration is a creature of contract. Stated differently, there must be a contractual basis to have a dispute resolved through binding arbitration. The Federal Arbitration Act (FAA) applies to transactions involving interstate commerce. Oftentimes, lawsuits are filed despite an arbitration provision in a contract because parties can, if they desire, waive their rights to have their dispute resolved through binding arbitration. In what should not be a shocker, the United States Supreme Court in Smith v. Spizzirri, 144 S.Ct. 1173, 1178 (2024), held that when a federal “district court finds that a lawsuit involves an arbitrable dispute, and a party requests a stay pending arbitration, section 3 of the FAA compels the court to stay the proceeding.” Dismissing the lawsuit should not be the option. Staying the lawsuit should. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Rhode Island Sues 13 Industry Firms Over Flawed Interstate Bridge

September 23, 2024 — Richard Korman - Engineering News-Record
In an attempt to recoup any money Rhode Island will owe to others for rerouting traffic on half of a high-volume interstate bridge in Providence after structural flaws had been detected, the state Dept. of Transportation filed a lawsuit Aug. 16 against 13 engineers and contractors that had inspected or performed work on the Washington Bridge in the last decade. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story...

General Contractor Gets Fired [Upon] for Subcontractor’s Failure to Hire Apprentices

September 23, 2024 — Garret Murai - California Construction Law Blog
As most public works contractors know, Labor Code section 1777.5 requires the hiring of apprentices on public works projects and, under Labor Code section 1777.7, violations are subject to civil penalties of up $100/day and up to $300/day days for repeated violations within a three-year period. In Lusardi Construction Co. v. Dept. of Industrial Relations, 102 Cal.App.5th (2024), a prime contractor learned the hard way that not only could it be penalized for its failure to hire apprentices but that it could also be liable for its subcontractor’s failure to hire apprentices. Forewarned is to be forearmed. The Lusardi Construction Case In 2014, general contractor Lusardi Construction Company hired subcontractor Pro Works Contracting to perform iron reinforcing work on a public works project owned by the San Marcos Unified School District. Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Hard to Believe It, Construction Law Musings is 16

January 07, 2025 — Christopher G. Hill - Construction Law Musings
On this date back in 2008 (wow, that seems so long ago), I began Construction Law Musings on the Blogger platform with a brief announcement. Little did I know that this corner of the internet (or is it Blawgosphere?) would still be around in 2024! In the time since I made that short entry 16 years ago (I know, I can’t believe it either), I’ve met several construction lawyers here in Virginia who refer to me as the “blog guy.” To be recognized for the work I do here at Construction Law Musings, something that benefits me (and I hope the readers), and which I do for the fun of it, is an honor. The blog has since taken on a life of its own in many respects, allowing me to meet some of the great construction pros who have provided a guest post or two for Musings and added their different perspectives. Musings also kept me up on at least most of the trends in Virginia construction law by making me post consistently (though sometimes less consistently than others). Now, around 975 posts and 16 years later, I find it hard to believe that so much time has passed and effort has been put into what started on a whim and the plan that I’d post thoughts on the legal landscape and construction from the perspective of a Virginia construction lawyer. Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

ANAHEIM CALIFORNIA BUILDING CONSULTANT DIRECTORY AND CAPABILITIES