Seattle Washington Building Consultant Directory

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

DIR Public Works Registration System Down, Public Works Contractors Not to be Penalized

July 15, 2024 — Garret Murai - California Construction Law Blog
In a bit of a major freak-out this past Friday, June 28, 2024, public works contractors with Department of Industrial Relations (“DIR”) registrations expiring on June 30, 2024 were unable to renew their public works registrations. Those who had submitted checks were not receiving responses, DIR was not accepting online payments, and there was no telephone number or address to contact the DIR about the issue. This, of course, could have been a big deal since Labor Code section 1725.5 prohibits contractors and subcontractors from bidding on, being listed in a bid, or being awarded a public works contract unless registered with the DIR. Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Five Issues to Consider in Government Contracting (Or Any Contracting!)

September 02, 2024 — David Adelstein - Florida Construction Legal Updates
The appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting. Issue #1- Patently Ambiguous Specifications The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Storm Debby Is Deadly — Because It’s Slow

September 16, 2024 — Brian K Sullivan - Bloomberg
Tropical Storm Debby has killed at least five people as it churns across the US East, where it’s expected to inflict $1 billion or more in damage and losses. One reason for the storm’s destructive power: It’s moving very slowly. Although Debby came ashore with hurricane-strength winds, its rainfall — forecast to exceed two feet in some areas — is even more dangerous. The St. Marys River in northern Florida rose more than 10 feet in one day, while New York will likely see downpours from Debby later in the week. Homes, businesses and farms may be deluged, putting crops and infrastructure at risk. Read the full story...
Reprinted courtesy of Brian K Sullivan, Bloomberg

Extreme Heat, Smoke Should Get US Disaster Label, Groups Say

July 15, 2024 — Jennifer A Dlouhy - Bloomberg
Activists are petitioning the US government to formally classify extreme heat and wildfire smoke as major disasters, as soaring temperatures threaten to set records across much of the country. In a petition filed with the Federal Emergency Management Agency, they seek to unlock new funding to help communities address such events before they strike, with money for air filters that strip out smoke and rooftop solar systems that can supply electricity when demand overwhelms power grids. Climate change has made fatal heat waves more intense and frequent, while hotter, drier conditions stoke the risk of fires that can blanket the US in toxic smoke. An estimated 2,300 people in the US died from heat-related illness in 2023, the hottest year on record. And heavy smoke from wildfires in Canada last year traveled as far south as Georgia, prompting people to shelter inside and canceling flights in some of the largest US cities. Read the full story...
Reprinted courtesy of Jennifer A Dlouhy, Bloomberg

When Every Drop Matters, Cities Turn to Watertech

November 25, 2024 — James B. Bobotek - Gravel2Gavel Construction & Real Estate Law Blog
We all need water to survive—but access to the liquid lifeline isn’t always a given. With a shifting climate and ever-increasing agricultural and industrial demands on this limited commodity, UNICEF predicts that by 2025, half of the world’s population could be living in areas facing water scarcity. On top of the obvious resource drains, many countries are losing surprising amounts of potable water to leaks. For example, in the United States alone, an estimated 6 billion gallons of treated drinking water seep out of its supply every day due to aging pipelines and undetected leaks. “Smart” water innovations may offer conservation solutions, though. As part of an overall smart city scheme, where internet of things (IoT) devices work hand-in-hand with AI to improve daily life, many municipalities are giving their water systems a makeover. From new meters to irrigation and pipeline maintenance, we look at some of the key intelligent technologies that endeavor to improve how we harness our water supply. Read the full story...
Reprinted courtesy of James B. Bobotek, Pillsbury
Mr. Bobotek may be contacted at james.bobotek@pillsburylaw.com

Let’s Get Surety Podcast – #126 Building the Future: AI, Construction and Law

December 31, 2024 — Denis Serkin - Peckar & Abramson, P.C.
Denis Serkin, partner in P&A’s New York and New Jersey offices, joins the latest episode of the NASBP podcast “Let’s Get Surety” to delve into the transformative impact of AI on the construction industry and construction law. In this insightful discussion, Denis explores how AI tools are already enhancing design and supply chains and shares his vision for AI’s eventual integration across every facet of the industry. Read the full story...
Reprinted courtesy of Denis Serkin, Peckar & Abramson, P.C.
Mr. Serkin may be contacted at dserkin@pecklaw.com

Real Estate & Construction News Roundup (10/16/24) – Chevron Ruling’s Impact on Construction Industry, New Kind of Public Housing and Policy Recommendations from Sustainable Building Groups

November 11, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, Hurricane Helene affects infrastructure, California Gov. Gavin Newsom signs bills aimed at renter protections, Federal Reserve kick-off rate-easing cycle, and more!

Hurricane Helene illustrates how communities and infrastructure across the U.S. are unprepared for the extreme weather driven by climate change. (Julie Strupp, Construction Dive)
The Supreme Court’s June Chevron ruling will likely have a seismic impact on laws that pertain to the construction industry. (Julie Strupp, Construction Dive)
California Gov. Gavin Newsom signed three bills changing renter protection practices in the state last month including new requirements for security deposit deductions and restrictions on certain fees. (Mary Salmonsen, Multifamily Dive)

Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

SEATTLE WASHINGTON BUILDING CONSULTANT DIRECTORY AND CAPABILITIES